承包工程合同

1,Contract for Construction of Refrigerator Factory,This Contract is made this 15th day of October，20by and between AA Co. Assab，Ethiopia（hereinafter called the Employer）and BB Engineering Corporation，Guangzhou，China（hereinafter called the Contractor),2,基本词汇和短语,Assab，Ethiopia:埃塞俄比亚阿萨布Engineering Corporation:工程公司,3,电冰箱工厂建造承包合同,本合同于20年10月15日由埃塞俄比亚阿萨布AA公司（以下称雇主）与中国广州BB工程公司（以下称承包人）签订。,4,Contract for Construction of Refrigerator Factory,WHEREAS the Ethiopian Tenders Committee has awarded contract to the Contractor；andWHEREAS the Employer and the Contractor are willing to enter into this Contract.NOW THEREFORE，the both Parties hereby agree as follows：,5,基本词汇和短语,WHEREAS:鉴于Tenders Committee:投标委员会award:授予，奖给，判给NOW THEREFORE:据此、 因此 hereby:特此，以此种方式,6,电冰箱工厂建造承包合同,鉴于埃塞俄比亚投标委员会已经选中承包人得标，以及鉴于雇主与承包人都愿签订本合同，因此，兹特由双方约定如下：,7,Contract for Construction of Refrigerator Factory,Article 1 This Contract is entered into on the basis of bidding and the following documents shall be deemed to form an integral part of this Contract，namely：（1）the Invitation to Bid；（2）the General Instructions and Conditions；（3）the Requirement Schedule；and（4）the Contractors Quotation，including supporting documentation,8,基本词汇和短语,bid:投标win the bidding ：中标form an integral part of:构成不可分割的一部分the Invitation to Bid:招标书，招标公告the General Instructions:一般规定the Requirement Schedule要货计划表quote：1.提到以支持某论点 2.报(价); 开(价) 3.举例 quotation：报价、行情、引文the Contractors Quotation:承包商报价supporting documentation:相关证明文件,9,电冰箱工厂建造承包合同,第一条 本合同是在投标的基础上达成的，下列文件必须是本合同的组成部分：1)招标书；2)一般规定和条件；3)要货计划表；4)承包人的报价单及有关证件。,10,Contract for Construction of Refrigerator Factory,Article 2 The Employer shall make a prepayment of 20% of the contract value to the Contractor within 10 days after signing this Contract. The Contractor shall furnish the Employer with a banks Letter of Guarantee to be valid till the date of full reimbursement of the amount of prepayment.,11,基本词汇和短语,make a prepayment of:预先支付reimbursement:退款，偿还，赔偿,12,电冰箱工厂建造承包合同,第二条 雇主应于签约后10天内向承包人支付相当于承包合同价值20的预付款；承包人则应向雇主提供一份银行保证书，其有效期直到预付款金额全部扣还为止。,13,Contract for Construction of Refrigerator Factory,The reimbursement of the prepayment shall be effected by deducting the monthly payments made by the Employer to the Contractor for the completed portion of the Works in the same percentage as the prepayment bears to the total contract value.,14,基本词汇和短语,the completed portion of the Works:工程的完工部分,15,电冰箱工厂建造承包合同,预付款的扣还办法，是由雇主在每月向承包人支付部分竣工工程付款时，按预付款占承包总价的相同比例分期扣除。,16,Contract for Construction of Refrigerator Factory,Article 3 The Contractor shall assign and send out the project manager，technicians，workers，accountants，interpreters，etc.（hereinafter called the Personnel）to the construction site within 30 days after signing this Contract. The Employer shall complete all the necessary entry procedures for the Personnel.,17,基本词汇和短语,send out:派出accountant:会计entry procedures:入境手续,18,电冰箱工厂建造承包合同,第三条 承包人应在签约后30天内向工地派出工程经理、技术员、工人、会计、翻译等（以下称人员）。雇主应为人员办理一切入境手续。,19,Contract for Construction of Refrigerator Factory,Article 4 The Contractor shall be responsible for doing the following work：（1）Examining the drawings and technical specifications of the project；（2）Making out the operation plan and progress schedule and the list of machinery，equipment and materials required for carrying out the project for approval of the engineer appointed by the Employer（hereinafter called the Engineer)；,20,基本词汇和短语,technical specifications:技术规范progress schedule:工程进度表,21,电冰箱工厂建造承包合同,第四条 承包人应负责下列工作：1）审查工程图纸、技术规范；2）草拟施工计划、工程进度表、施工需用的机械、设备和材料名单等供雇主委派的工程师（以下称工程师）批准；,22,Contract for Construction of Refrigerator Factory,（3）Clearing up the construction site and leveling the ground；（4）Constructing some temporary Works such as workers housing，garages and warehouses for temporary use；（5）Giving adequate protection to all the machinery，equipment，tools，materials provided by the Employer and the completed and uncompleted Works during the period of construction.,23,基本词汇和短语,cleare up:清理level：使平坦，变平；水平线，水平level the ground:平整土地garage:车库warehouse:仓库,24,电冰箱工厂建造承包合同,3)清理建筑工地、平整土地；4)建造某些临时工程，如工人宿舍、停车场、仓库等供临时使用；5)在建筑期间，对雇主提供的机械、设备、工具、材料以及对已竣工和尚未竣工的工程，给予妥善的保护。,25,Contract for Construction of Refrigerator Factory,Article 5 It is mutually understood and agreed by both Parties that the Engineer shall carry out such duties in issuing decisions，certifications and orders as are specified in the Contract and supervising the Works and examining any material or workmanship to be used in connection with the Works.,26,基本词汇和短语,issuing decisions:发布决定workmanship:工艺,27,电冰箱工厂建造承包合同,第五条 双方同意工程师应按合同规定履行发布决定、证明、命令，监督工程，检查使用的材料、工艺等的职责。,28,Contract for Construction of Refrigerator Factory,The Contractor and its personnel shall carry out the Engineers instructions and offer convenience to his work. If the Contractor is dissatisfied with any decision of the Engineer，he shall be entitled to explain the reason for the Engineers consideration and the Engineer shall thereupon confirm，reverse or vary such decision in due time.,29,基本词汇和短语,instructions:指示convenience:方便thereupon:因此，于是reverse:推翻，反转；否定；vary:使变化，改变, 修改in due time:及时,30,电冰箱工厂建造承包合同,承包人及其人员应该执行工程师的指示，并对他的工作提供方便。如果对工程师的决定不满意，承包人有权讲明理由供工程师考虑。工程师应该根据所提理由及时肯定、否定或修改他的决定。,31,Contract for Construction of Refrigerator Factory,Article 6 6. 1 The Contractor shall commence the Works on site from the receipt of a written order to this effect from the Engineer and shall complete the whole Works within 14 months as the progress schedule bid in the Contractors Quotation.,32,基本词汇和短语,commence:开始to this effect:大意是如此 the progress schedule :工程进度表the Contractors Quotation:承包商报价,33,电冰箱工厂建造承包合同,第六条6. 1 承包人应从接到工程师的书面开工命令之日起立即开工，并按投标报价单中所报的工程进度，于14个月内完成全部工程。,34,Contract for Construction of Refrigerator Factory,6.2 In the event the Contractor fails to complete the Works in time owing to such reasons that the Contractor shall be liable therefor，the Contractor shall pay a penalty for such default based on one out of a thousand（1）of the total price for the Works per day，but the total amount of penalties shall not exceed 10% of the contract value.,35,基本词汇和短语,in the event:如果be liable therefor:承担责任penalty:罚金；不利，害处；点球default:违约,36,电冰箱工厂建造承包合同,6.2 如果由于应该自负责任的原因未能按时完成工程，承包人应为此支付每日按工程总价1计算的罚金。但罚款的总金额不得超过合同总价的10% 。,37,Contract for Construction of Refrigerator Factory,6. 3 The Contractor shall not be liable for any delay caused by：（1）Increasing of work by the Employer；（2）Short supply of materials；（3）Stoppage of electricity or water；and（4）Force Majeure.In the above cases，the time limit for completion of the Works shall be extended correspondingly.,38,基本词汇和短语,the time limit for completion:完工限期correspondingly:相应地,39,电冰箱工厂建造承包合同,6.3 承包人对下列原因造成的延误不负责任：1)雇主增加工程量；2)材料缺供；3)停电停水；4)不可抗力。在上述情况下，工程竣工的时限应该相应地予以延长。,40,Contract for Construction of Refrigerator Factory,Article 7 In case the Employer has amended，increased or decreased its project of construction work，the corresponding increase or decrease of total price shall be calculated as per the unit price of the Contract. Should there be newly increased items of work，the price of such items shall be negotiated and fixed by both Parties.,41,基本词汇和短语,amend:修改as per:根据,42,电冰箱工厂建造承包合同,第七条 如果雇主修改、增加、减少工程建设项目，由此增加或减少的金额，应按合同的单价计算。如系新增工程项目，则其价格须由双方商定。,43,Contract for Construction of Refrigerator Factory,Article 88. 1 The total price of the Works shall be US，the same amount as bid in the Contractors Quotation.8. 2 Payments shall be effected by 14 monthly installments.,44,基本词汇和短语,installments: n. 部分，分期付款,45,电冰箱工厂建造承包合同,第八条8.1 承包工程总价应等于承包人在投标时所报的总金额，即美元。8.2 每月付款一次，分14次付清。,46,Contract for Construction of Refrigerator Factory,8.3 The Contractor shall send to the Engineer once in every month an account giving particulars of the actual quantities of the Works completed within the month for the Engineers certification. The Employer shall effect the monthly payment against the account and the certification after deducting the portion of the prepayment as stated in Article 2 hereof.,47,基本词汇和短语,particulars:细节hereof:于此，关于此点；,48,电冰箱工厂建造承包合同,8.3 承包人应将每月实际完成的工程数量，详列账目报请工程师证明。雇主应根据这个账目和证明，在扣除本合同第二条规定的部分预付款之后，每月付款一次。,49,Contract for Construction of Refrigerator Factory,8. 4 When the whole of the Works has been completed and has passed the final test，the Contractor may give a written notice to that effect to the Engineer and the Engineer shall issue a Certificate of Completion of Works to the Contractor，with a copy to the Employer. The Employer shall pay to the Contractor the balance of the unpaid amount for the Works within 20 days after receipt of the Certificate.,50,基本词汇和短语,pass the final test:通过最后测试，通过验收a Certificate of Completion of Works:完工证明，竣工证明书balance：结欠，结清（余额）the balance of the unpaid amount:未支付的余额,51,电冰箱工厂建造承包合同,8.4 当全部工程竣工并通过最后验收时，承包人应将此结果以书面通知工程师。工程师应向承包人颁发竣工证明书，并将副本抄送雇主。雇主应在收到竣工证明书后20天内，将尚未支付的工程余款全部付给承包人。,52,Contract for Construction of Refrigerator Factory,8.5 In case the Employer delays in payment of the project cost to the Contractor，interest shall be chargeable at 10% per month on the amount and for the number of days in arrears.Article 9The Contractor shall remove from the site all the machinery，equipment，temporary works and any unused materials within 2 weeks after delivery of the completed Works.,53,基本词汇和短语,chargeable:可以控诉的,可记在某项账目上的arrears：n. 拖欠；拖延 in arrears:拖欠,拖延,落后 machinery:机械,54,电冰箱工厂建造承包合同,8.5 如果雇主拖延支付工程款项，则应按拖欠的金额和天数，以月息10的利率计付利息。第九条在全部工程完成和交货后两周之内，承包人应将全部机械、设备、临时工程、未用的材料从工地撤走。,55,Contract for Construction of Refrigerator Factory,Article 10The Contractor shall warrant the promised condition of the Works and provide free and periodic maintenance service for 5 years after the date of receiving the Works by the Employer；but the Contractor shall not be liable for Force Majeure or misuse of the Works by the Employer.,56,基本词汇和短语,warrant：保证promised:承诺的，允诺的periodic maintenance service:定期维修服务,57,电冰箱工厂建造承包合同,第十条 承包人应保证该项工程的良好状态，并在雇主验收工程之后免费定期维修服务5年。但对于不可抗力和雇主错误使用该项工程，承包人不予负责。,58,Contract for Construction of Refrigerator Factory,Article 11 The Contractors Personnel shall abide by the laws，rules and regulations of Ethiopia and respect the local habits and customs and not partake in any local political activities. The Employer shall secure the safety of the Contractors Personnel at the site and in their camp area.,59,基本词汇和短语,respect:尊重secure the safety of:保证的安全,60,电冰箱工厂建造承包合同,第十一条 承包人的人员，应遵守埃塞俄比亚的法律、条例、规章，尊重当地传统习俗，不参加当地任何政治活动。雇主应保证人员在工地和营房驻地的安全。,61,Contract for Construction of Refrigerator Factory,Article 12 All disputes or differences which may arise and cannot be settled through friendly consultation between the two Parties shall be settled by arbitration in London，England，in accordance with the Rules of Conciliation and Arbitration of the International Chamber of Commerce. The award shall be final and binding upon both Parties.,62,基本词汇和短语,differences:分歧,63,电冰箱工厂建造承包合同,第十二条 对于双方之间发生的不能友好协商解决的争议和分歧，应在伦敦按照国际商会的调解和仲裁规则予以仲裁解决。这个裁决是终局的，对双方均有约束力。,64,Contract for Construction of Refrigerator Factory,Article 13This Contract is made in the English language as the original text，irrespective of translation into the Chinese and the Ethiopian languages. This Contract shall be interpreted in accordance with the laws of the United Kingdom without prejudice to the application of the rules of arbitration.,65,基本词汇和短语,the original text:正本，原件irrespective of:不管