承包工程合同课件

1、承包工程合同1 Contract for Construction of Refrigerator Factory This Contract is made this 15th day of October，20by and between AA Co. Assab，Ethiopia（hereinafter called the Employer）and BB Engineering Corporation，Guangzhou，China （hereinafter called the Contractor) 承包工程合同2 基本词汇和短语 Assab，Ethiopia:埃塞俄比亚阿萨布 E

2、ngineering Corporation:工程公司工程公司 承包工程合同3 电冰箱工厂建造承包合同 本合同于20年10月15日由埃塞俄比亚阿 萨布AA公司（以下称雇主）与中国广州BB 工程公司（以下称承包人）签订。 承包工程合同4 Contract for Construction of Refrigerator Factory WHEREAS the Ethiopian Tenders Committee has awarded contract to the Contractor；and WHEREAS the Employer and the Contractor are willi

3、ng to enter into this Contract. NOW THEREFORE，the both Parties hereby agree as follows： 承包工程合同5 基本词汇和短语 WHEREAS:鉴于鉴于 Tenders Committee:投标委员会投标委员会 award:授予，奖给，判给授予，奖给，判给 NOW THEREFORE:据此、据此、 因此因此 hereby:特此，以此种方式特此，以此种方式 承包工程合同6 电冰箱工厂建造承包合同 鉴于埃塞俄比亚投标委员会已经选中承包 人得标，以及鉴于雇主与承包人都愿签订 本合同，因此，兹特由双方约定如下： 承包工程合

4、同7 Contract for Construction of Refrigerator Factory Article 1 This Contract is entered into on the basis of bidding and the following documents shall be deemed to form an integral part of this Contract，namely： （1）the Invitation to Bid； （2）the General Instructions and Conditions； （3）the Requirement

5、Schedule；and （4）the Contractors Quotation，including supporting documentation 承包工程合同8 基本词汇和短语 bid:投标投标 win the bidding ：中标：中标 form an integral part of:构成不可分割的一部分构成不可分割的一部分 the Invitation to Bid:招标书，招标公告招标书，招标公告 the General Instructions:一般规定一般规定 the Requirement Schedule要货计划表要货计划表 quote：1. 提到提到以支持某论点以支

6、持某论点 2. 报报(价价); 开开(价价) 3. 举例举例 quotation：报价、行情、引文：报价、行情、引文 the Contractors Quotation:承包商报价承包商报价 supporting documentation:相关证明文件相关证明文件 承包工程合同9 电冰箱工厂建造承包合同 第一条 本合同是在投标的基础上达成的， 下列文件必须是本合同的组成部分： 1)招标书； 2)一般规定和条件； 3)要货计划表； 4)承包人的报价单及有关证件。 承包工程合同10 Contract for Construction of Refrigerator Factory Article

7、 2 The Employer shall make a prepayment of 20% of the contract value to the Contractor within 10 days after signing this Contract. The Contractor shall furnish the Employer with a banks Letter of Guarantee to be valid till the date of full reimbursement of the amount of prepayment. 承包工程合同11 基本词汇和短语

8、make a prepayment of:预预先支付先支付 reimbursement:退款，偿还，赔偿退款，偿还，赔偿 承包工程合同12 电冰箱工厂建造承包合同 第二条 雇主应于签约后10天内向承包人 支付相当于承包合同价值20的预付款； 承包人则应向雇主提供一份银行保证书， 其有效期直到预付款金额全部扣还为止。 承包工程合同13 Contract for Construction of Refrigerator Factory The reimbursement of the prepayment shall be effected by deducting the monthly pay

9、ments made by the Employer to the Contractor for the completed portion of the Works in the same percentage as the prepayment bears to the total contract value. 承包工程合同14 基本词汇和短语 the completed portion of the Works:工程的工程的 完工部分完工部分 承包工程合同15 电冰箱工厂建造承包合同 预付款的扣还办法，是由雇主在每月向承 包人支付部分竣工工程付款时，按预付款 占承包总价的相同比例分期扣

10、除。 承包工程合同16 Contract for Construction of Refrigerator Factory Article 3 The Contractor shall assign and send out the project manager，technicians， workers，accountants，interpreters，etc. （hereinafter called the Personnel）to the construction site within 30 days after signing this Contract. The Employer

11、shall complete all the necessary entry procedures for the Personnel. 承包工程合同17 基本词汇和短语 send out:派出派出 accountant:会计会计 entry procedures:入境手续入境手续 承包工程合同18 电冰箱工厂建造承包合同 第三条 承包人应在签约后30天内向工地 派出工程经理、技术员、工人、会计、翻 译等（以下称人员）。雇主应为人员办理 一切入境手续。 承包工程合同19 Contract for Construction of Refrigerator Factory Article 4 Th

12、e Contractor shall be responsible for doing the following work： （1）Examining the drawings and technical specifications of the project； （2）Making out the operation plan and progress schedule and the list of machinery， equipment and materials required for carrying out the project for approval of the e

13、ngineer appointed by the Employer （hereinafter called the Engineer)； 承包工程合同20 基本词汇和短语 technical specifications:技术规范技术规范 progress schedule:工程进度表工程进度表 承包工程合同21 电冰箱工厂建造承包合同 第四条 承包人应负责下列工作： 1）审查工程图纸、技术规范； 2）草拟施工计划、工程进度表、施工需用 的机械、设备和材料名单等供雇主委派的 工程师（以下称工程师）批准； 承包工程合同22 Contract for Construction of Refrige

14、rator Factory （3）Clearing up the construction site and leveling the ground； （4）Constructing some temporary Works such as workers housing，garages and warehouses for temporary use； （5）Giving adequate protection to all the machinery，equipment，tools，materials provided by the Employer and the completed a

15、nd uncompleted Works during the period of construction. 承包工程合同23 基本词汇和短语 cleare up:清理清理 level：使平坦，变平；水平线，水平：使平坦，变平；水平线，水平 level the ground:平整土地平整土地 garage:车库车库 warehouse:仓库仓库 承包工程合同24 电冰箱工厂建造承包合同 3)清理建筑工地、平整土地； 4)建造某些临时工程，如工人宿舍、停车 场、仓库等供临时使用； 5)在建筑期间，对雇主提供的机械、设备、 工具、材料以及对已竣工和尚未竣工的工 程，给予妥善的保护。 承包工程合同

16、25 Contract for Construction of Refrigerator Factory Article 5 It is mutually understood and agreed by both Parties that the Engineer shall carry out such duties in issuing decisions， certifications and orders as are specified in the Contract and supervising the Works and examining any material or w

17、orkmanship to be used in connection with the Works. 承包工程合同26 基本词汇和短语 issuing decisions:发布决定发布决定 workmanship:工艺工艺 承包工程合同27 电冰箱工厂建造承包合同 第五条 双方同意工程师应按合同规定履 行发布决定、证明、命令，监督工程，检 查使用的材料、工艺等的职责。 承包工程合同28 Contract for Construction of Refrigerator Factory The Contractor and its personnel shall carry out the E

18、ngineers instructions and offer convenience to his work. If the Contractor is dissatisfied with any decision of the Engineer，he shall be entitled to explain the reason for the Engineers consideration and the Engineer shall thereupon confirm，reverse or vary such decision in due time. 承包工程合同29 基本词汇和短语

19、 instructions:指示指示 convenience:方便方便 thereupon:因此，于是因此，于是 reverse:推翻，反转；否定；推翻，反转；否定； vary:使变化，改变使变化，改变, 修改修改 in due time:及时及时 承包工程合同30 电冰箱工厂建造承包合同 承包人及其人员应该执行工程师的指示， 并对他的工作提供方便。如果对工程师的 决定不满意，承包人有权讲明理由供工程 师考虑。工程师应该根据所提理由及时肯 定、否定或修改他的决定。 承包工程合同31 Contract for Construction of Refrigerator Factory Articl

20、e 6 6. 1 The Contractor shall commence the Works on site from the receipt of a written order to this effect from the Engineer and shall complete the whole Works within 14 months as the progress schedule bid in the Contractors Quotation. 承包工程合同32 基本词汇和短语 commence:开始开始 to this effect:大意是如此大意是如此 the pr

21、ogress schedule :工程进度表工程进度表 the Contractors Quotation:承包商报价承包商报价 承包工程合同33 电冰箱工厂建造承包合同 第六条 6. 1 承包人应从接到工程师的书面开工 命令之日起立即开工，并按投标报价单中 所报的工程进度，于14个月内完成全部工 程。 承包工程合同34 Contract for Construction of Refrigerator Factory 6.2 In the event the Contractor fails to complete the Works in time owing to such reason

22、s that the Contractor shall be liable therefor，the Contractor shall pay a penalty for such default based on one out of a thousand（1）of the total price for the Works per day，but the total amount of penalties shall not exceed 10% of the contract value. 承包工程合同35 基本词汇和短语 in the event:如果如果 be liable ther

23、efor:承担责任承担责任 penalty:罚金；不利，害处；点球罚金；不利，害处；点球 default:违约违约 承包工程合同36 电冰箱工厂建造承包合同 6.2 如果由于应该自负责任的原因未能按 时完成工程，承包人应为此支付每日按工 程总价1计算的罚金。但罚款的总金额不 得超过合同总价的10% 。 承包工程合同37 Contract for Construction of Refrigerator Factory 6. 3 The Contractor shall not be liable for any delay caused by： （1）Increasing of work by

24、 the Employer； （2）Short supply of materials； （3）Stoppage of electricity or water；and （4）Force Majeure. In the above cases，the time limit for completion of the Works shall be extended correspondingly. 承包工程合同38 基本词汇和短语 the time limit for completion:完工限期完工限期 correspondingly:相应地相应地 承包工程合同39 电冰箱工厂建造承包合同

25、6.3 承包人对下列原因造成的延误不负责 任： 1)雇主增加工程量； 2)材料缺供； 3)停电停水； 4)不可抗力。 在上述情况下，工程竣工的时限应该相应 地予以延长。 承包工程合同40 Contract for Construction of Refrigerator Factory Article 7 In case the Employer has amended，increased or decreased its project of construction work，the corresponding increase or decrease of total price sha

26、ll be calculated as per the unit price of the Contract. Should there be newly increased items of work，the price of such items shall be negotiated and fixed by both Parties. 承包工程合同41 基本词汇和短语 amend:修改修改 as per:根据根据 承包工程合同42 电冰箱工厂建造承包合同 第七条 如果雇主修改、增加、减少工程 建设项目，由此增加或减少的金额，应按 合同的单价计算。如系新增工程项目，则 其价格须由双方商定

27、。 承包工程合同43 Contract for Construction of Refrigerator Factory Article 8 8. 1 The total price of the Works shall be US，the same amount as bid in the Contractors Quotation. 8. 2 Payments shall be effected by 14 monthly installments. 承包工程合同44 基本词汇和短语 installments: n. 部分，分期付款部分，分期付款 承包工程合同45 电冰箱工厂建造承包合同

28、第八条 8.1 承包工程总价应等于承包人在投标时 所报的总金额，即美元。 8.2 每月付款一次，分14次付清。 承包工程合同46 Contract for Construction of Refrigerator Factory 8.3 The Contractor shall send to the Engineer once in every month an account giving particulars of the actual quantities of the Works completed within the month for the Engineers certif

29、ication. The Employer shall effect the monthly payment against the account and the certification after deducting the portion of the prepayment as stated in Article 2 hereof. 承包工程合同47 基本词汇和短语 particulars:细节细节 hereof:于此，关于此点；于此，关于此点； 承包工程合同48 电冰箱工厂建造承包合同 8.3 承包人应将每月实际完成的工程数量， 详列账目报请工程师证明。雇主应根据这 个账目和证明

30、，在扣除本合同第二条规定 的部分预付款之后，每月付款一次。 承包工程合同49 Contract for Construction of Refrigerator Factory 8. 4 When the whole of the Works has been completed and has passed the final test， the Contractor may give a written notice to that effect to the Engineer and the Engineer shall issue a Certificate of Completion

31、 of Works to the Contractor，with a copy to the Employer. The Employer shall pay to the Contractor the balance of the unpaid amount for the Works within 20 days after receipt of the Certificate. 承包工程合同50 基本词汇和短语 pass the final test:通过最后测试，通过验收通过最后测试，通过验收 a Certificate of Completion of Works:完工完工 证明，竣

32、工证明书证明，竣工证明书 balance：结欠，结清（余额）：结欠，结清（余额） the balance of the unpaid amount:未支付的未支付的 余额余额 承包工程合同51 电冰箱工厂建造承包合同 8.4 当全部工程竣工并通过最后验收时， 承包人应将此结果以书面通知工程师。工 程师应向承包人颁发竣工证明书，并将副 本抄送雇主。雇主应在收到竣工证明书后 20天内，将尚未支付的工程余款全部付给 承包人。 承包工程合同52 Contract for Construction of Refrigerator Factory 8.5 In case the Employer dela

33、ys in payment of the project cost to the Contractor，interest shall be chargeable at 10% per month on the amount and for the number of days in arrears. Article 9 The Contractor shall remove from the site all the machinery，equipment，temporary works and any unused materials within 2 weeks after deliver

34、y of the completed Works. 承包工程合同53 基本词汇和短语 chargeable:可以控诉的可以控诉的,可记在某项账目上可记在某项账目上 的的 arrears：n. 拖欠；拖延拖欠；拖延 in arrears:拖欠拖欠,拖延拖延,落后落后 machinery:机械机械 承包工程合同54 电冰箱工厂建造承包合同 8.5 如果雇主拖延支付工程款项，则应按 拖欠的金额和天数，以月息10的利率计 付利息。 第九条 在全部工程完成和交货后两周之内，承包 人应将全部机械、设备、临时工程、未用 的材料从工地撤走。 承包工程合同55 Contract for Construction

35、 of Refrigerator Factory Article 10 The Contractor shall warrant the promised condition of the Works and provide free and periodic maintenance service for 5 years after the date of receiving the Works by the Employer；but the Contractor shall not be liable for Force Majeure or misuse of the Works by

36、the Employer. 承包工程合同56 基本词汇和短语 warrant：保证：保证 promised:承诺的，允诺的承诺的，允诺的 periodic maintenance service:定期维修服务定期维修服务 承包工程合同57 电冰箱工厂建造承包合同 第十条 承包人应保证该项工程的良好状 态，并在雇主验收工程之后免费定期维修 服务5年。但对于不可抗力和雇主错误使用 该项工程，承包人不予负责。 承包工程合同58 Contract for Construction of Refrigerator Factory Article 11 The Contractors Personnel

37、shall abide by the laws，rules and regulations of Ethiopia and respect the local habits and customs and not partake in any local political activities. The Employer shall secure the safety of the Contractors Personnel at the site and in their camp area. 承包工程合同59 基本词汇和短语 respect:尊重尊重 secure the safety

38、of:保证保证的安全的安全 承包工程合同60 电冰箱工厂建造承包合同 第十一条 承包人的人员，应遵守埃塞俄 比亚的法律、条例、规章，尊重当地传统 习俗，不参加当地任何政治活动。雇主应 保证人员在工地和营房驻地的安全。 承包工程合同61 Contract for Construction of Refrigerator Factory Article 12 All disputes or differences which may arise and cannot be settled through friendly consultation between the two Parties s

39、hall be settled by arbitration in London， England，in accordance with the Rules of Conciliation and Arbitration of the International Chamber of Commerce. The award shall be final and binding upon both Parties. 承包工程合同62 基本词汇和短语 differences:分歧分歧 承包工程合同63 电冰箱工厂建造承包合同 第十二条 对于双方之间发生的不能友好 协商解决的争议和分歧，应在伦敦按照

40、国 际商会的调解和仲裁规则予以仲裁解决。 这个裁决是终局的，对双方均有约束力。 承包工程合同64 Contract for Construction of Refrigerator Factory Article 13 This Contract is made in the English language as the original text，irrespective of translation into the Chinese and the Ethiopian languages. This Contract shall be interpreted in accordance with the laws of the United Kingdom without prejudice to the application of the rules of arbitration. 承包工程合同65 基本词汇和短语 the original text:正本，原件正本，原件 irrespective of:不管，不顾，不论不管，不顾，不论 without prejudice to:在不影响在不影响的情况下，不违的情况下，不违 背背 The offer is accepted without prejudice to the cu