建设工程设计合同文本-中英文对照

1、建设工程设计合同文本 - 中英文对照 篇一：建设工程设计合同 （ 中英文对照版 ） 建设工程设计合同（二）（专业建设工程设计合同）Engineering Service Contract （n ）For（Professional Engineering Service ContractConstruction Project）工 程 名 称：工 程 地 点:合 同 编 号：（由设计人编填）设计证书等级：发 包 人：设 计 人：签 订 日 期:Name of the project:Location of the project:Contract No.:（Filled in by the De

2、signer）Level of the design certificate:Employer:Designer:Date of contract: November 25, XX监制中华人民共和国建设部 国家工商行政管理部Supervised by: Jiangsu Provincial Department of ConstructionJiangsu Provincial Administration for Industry and Commerce发包人：设计人 : 发包人委托设计人承担 工程设计，工程地点为 ，经双方协商一致，签订本合同，共同执 行。Employer: (Party

3、 A)Designer: (Party B)The Employer entrust the Designer to undertake the engineering design of the 10/ transformer station and the location for the project is within the plant of After friendly consultation, the Parties hereby sign this Contract as follows：第一条 本合同签订论据中华人民共和国合同法 、中华人民共和国建筑法和建设工程勘察设计市

4、场管理规定 。 国家及地方有关建设工程勘察设计管理法规和规章。 建设工程批准文件。Article 1 Basis for the conclusion of this Contract The Contract Law of the People ' s Republic of China;The Construction Law of the People 's Republic of China; Regulations on the Administration of the Market for Survey and Design of Engineering Cons

5、truction.National and local rules and regulations on the administration of the market for survey and design of engineering constructionApproval documents of the engineering construction第二条 设计依据 发包人给设计人的委托书或设计中标文件 发包人提交的基础资料 设计人采用的主要技术标准是：Article 2 Basis for design of the engineering constructionLett

6、er of Authority or documents on letter of acceptance provided by the Employer to the Designer.Basic materials submitted by the Employer.The main technological standards adopted by theDesigner is as follows:第三条 合同文件的优先次序 构成本合同的文件可视为是能互相说明的，如果合同文 件存在歧义或不一致，则根据如下优先次序来判断：合同书中标函(文件)发包人要求及委托书投标书Article 3

7、Priority of the contractual documentsThe several documents forming the Contract are to be taken as mutually explanatory of one another, but in case of ambiguities or discrepancies, the priority of the documents forming, the Contract shall be as follows:(1) The Contract;(2) The Letter of Acceptance (

8、documents);(3) Requirements of the Employer and letter of authority;(4) The Tender;第四条 本合同项目的名称、规模、阶段、投资及设计 内容(根据行业特点填写) Article 4 Name, size, stages, investment and content of design(which may be filled in according to the characteristics of the industry)第五条 发包人向设计人提交的有关资料、文件及时间 序号 资料及文件名称 份数 提交日期

9、有关事宜Article 5 Materials and documents delivered by the Employer to the Designer and time for delivery of materials and documents1. ;2. ;3. Official reply of the power supply department on consent of the power supply.第六条 设计人向发包人交付的设计文件、份数、地点 及时间序号 资料及文件名称 份数 提交日期 有关事宜Article 6 Delivery of design docu

10、ments by the Designer to the constract issuing party and copies, location and time for the deliveryThe Designer shall deliver to the Employer all set of drawings of the electrical design with eight copies in total. And the Employer may take all drawings from the Wuxi Civil Engineering Construction I

11、nstitute Co.,Ltd. on ,第七条 费用双方商定，本合同的设计费为 万元。收费依据和计算方法按国家和地方有关规定执行，国 家和地方没有规定的，由双方商定。如果上述费用为估算设计费，则双方在初步设计审批后， 按批准的初步设计概算核算设计费。工程建设期间如遇概算 调整，则设计费也应做相应调整。Article 7 ChargesThe Parties agree that charges for the design hereunder shall be % of the total investment of the transformer (the appraised price

12、 of this contract shall be taken as basis). The basis for charges and the method of computing shall be in accordance with relevant national and local provisions. Where there are no relevant national and local provisions, it shall be discussed and determined by the Parties.第八条 支付方式 本合同生效后三天内，发包人支付设计费

13、总额的20%，计 万元作为定金 (合同结算时， 定金低作设计费) 。设计人提交 设计文件后三天内，发包人支付设计总额的 30%，计 万元；之后，发包人应按设计人所完成的施工图工作量比例，分期分批向设计人支付总设计费的 20%，计 万元，施工图完成后，发包人结清设计费，不留尾款。双方委托银行代付代收有关费用。Article 8 Terms of paymentWithin three days upon the effectiveness of this contract, the Employer shall pay 1% of RMB 1,800,000yuan, the appraised

14、 price of investment to the transformer, namely RMB1,8000 yuan as the down payment.( the down payment shall be counted as the charges for design upon settlement of the contract).The Designer shall submit eight sets of design documents to Party A for submission to the power supply department and the

15、Employer will pay % of RMB 1,800,000yuan, the appraised price of investment to the transformer, namely RMB 6,3000 yuan, without any remainder.The Parties shall entrust bank to collect and pay for relevant charges.第九条 双方责任发包人责任发包人按本合同第五条规定的内容，在规定的时间内向设计人提交基础资料及文件，并对其完整性、正确性及时限 负责。发包人不得要求设计人违反国家有关标准进行

16、设计。 发包人提交上述资料及文件超过规定期限 15 天以内，设计 人按本合同第六条规定的交付设计文件时间顺延；发包人交 付上述资料及文件超过规定期限 15 天以上时，设计人有权 重新确定提交设计文件的时间。Article 9 Responsibilities of the PartiesResponsibilities of the EmployerThe Employer shall submit to Designer basic materials and documents withinspecified period as provided in Article 5 of this

17、contract and shall be responsible for the completeness, accuracy and time limit of the materials and documents. The Employer shall not require the Designer to conduct design in violation of relevant national standards. In case there is a delay of less than 15 days exceeding the specified time limit

18、for the delivery of the above materials and documents by the Employer, the time limit for the Designer to deliver design documents shall be extended accordingly; in case there is a delay of more than 15 days exceeding the specified time limit for the delivery of the above materials and documents by

19、theEmployer, the Designer shall have the right to re-determine the time for delivery of the design documents.发包人变更委托设计项目、规模、条件或因提交的资料 错误，或所提交资料作较大修改，以致造成设计人设计返工 时，双方除另行协商签订补充协议(或另订合同) 、重新明 确有关条款外，发包人应按设计人所耗工作量向设计人支付 返工费。在未签订合同前发包人已同意，设计人为发包人所做的 各项设计工作，发包人应支付相应设计费。In case of the Designer' s rewor

20、k on the designresulted for changes of the engineering, size and conditions of the design by the Employer or mistakes of the materials submitted or major revision on the submitted materials, the Parties shall conclude supplementary agreement separately (or conclude additional agreement) and redefine

21、 relevant terms and conditions, and the Employer should pay charges for rework to the Designer according to the workload.The Employer has agreed before the conclusion of the contract that it will pay charges of design to the Designer for all the design works conducted by theDesigner.在合同履行期间，发包人要求终止或

22、解除合同，设计人 未开始设计工作的，不退还发包人已付的定金；已开始设计 工作的，发包人应根据设计人已进行的实际工作量，不足一 半时，按该阶段设计费的一半支付；超过一半时，按该阶段 设计费的全部支付。During the performance of the contract, if theEmployer requires to terminate or cancel the contract before the Designer starts the design work, the Designer will not return the down payment already pai

23、d by the Employer; if the Designer has started the design work, the Employer shall pay for the actual workload already done by the Designer. Whenthe actual workload of the design is less than half of the work at the stage, the Employer shall pay half of the payment for the design work at the stage.

24、When the actual workload of the design is more than half of the work at the stage, the Employer shall pay all the payment for the design work at the stage.发包人必须按合同规定支付定金，收到定金作为设计人设计开工的标志。未收到定金，设计人有权推迟设计工作的开工时问，且交付文件的时间顺延。The Employer should pay down payment as provided by the contract and receipt of

25、 down payment will be the symbol for the commencement of the design work by the Designer. The Designer shall have the right to put off the commencement date of the design work if it has not received the down payment and the time for delivery shall be extended accordingly.发包人应按本合同规定的金额和日期向设计人支付设 计费，每

26、逾期支付一天，应承担应支付金额千分之二的逾期 违约金，且设计人提交设计文件的时间顺延。逾期超过 30 天以上时，设计人有权暂停履行下阶段工作，并书面通知发 包人。发包人的上级或设计审批部门对设计文件不审批或本 合同项目停缓建，发包人均应支付应付的设计费。The Employer should pay charges for design to the Designer at the amount and date provided in this Contract. For each day of overdue payment, 2%o of theoverdue payment shall

27、 be paid as damages for overdue payment and the time for delivery by the Designer shall be extended accordingly. Where the delay of payment has exceeded 30 days, the Designer shall have the right to suspend the performance of the work at the next stage and give written notice to the Employer. In cas

28、e thehigher authority or competent department of design approval would not approve the design documents or the engineering construction of this contract is suspended or stopped, the Employer should pay the payable charges for design.发包人要求设计人比合同规定时间提前交付设计文件 时，须征得设计人同意，不得严重背离合理设计周期，且发 包人应支付赶工费。发包人应为设计

29、人派驻现场的工作人员提供工作、生活 及交通等方面的便利条件及必要的劳动保护装备。设计文件中选用的国家标准图、部标准图及地方标准图 由发包人负责解决。If the Employer require the Designer to deliverythe design documents in advance, it should get the prior consent of the Designer without serious deviation from the reasonable design circle, and the Employer shall pay the crush

30、 cost.The Employer should offer conveniences in aspects of working, living and traffic and necessary labor-protection equipments.The Employer shall be responsible for the national standard drawing, ministerial standard drawing and local standard drawings. 承担本项目外国专家来设计人办公室工作的接待费（包 括传真、电话、复印、办公等费用） 。9

31、 The Employer shall bear the expenses for receiving foreign expert in charge of the engineering to the Designer ' s office （including expenses on fax, telephone and office affairs）.设计人责任 设计人应按国家规定和合同约定的技术规范、标准进行 设计，按本合同第六条规定的内容、时间及份数向发包人交 付设计文件（出现、 、规定有关交付设计文件顺延的情况除 外）。并对提交的设计文件的质量负责。设计合理使用年限为 年

32、。 负责对外商的设计资料进行审查，负责该合同项目的设 计联络工作。Designer ' s responsibilitiesThe Designer should carry out design work in accordance with technological rules and standards provided in this contract or the state, and deliver design documents as the content, time and copies specified in Article 6 of this Contrac

33、t （except for the circumstances provided in Art. , , , under which thedelivery of design documents may be extended), and shall be responsible for the quality of the design documents.The design life of the engineering constructionshall be years.The Designer shall be responsible for the scrutiny on th

34、e foreign investor ' s design material and contact on the design of the engineering.设计人对设计文件出现的遗漏或错误负责修改或补充。 由于设计人设计错误造成工程质量事故损失，设计人除负责 采取补救措施外，应免收受损失部分的设计费，并根据损篇二：中英文对照 - 工程施工合同范本工程施工合同Contract合同编号 ( Contract NO. ) ： 签订日期 ( Date ) ： 发包方(简称甲方)Party A:承包方(简称乙方) ：Party B:根据中华人民共和国合同法以及其他有关法律法 规规定的

35、原则， 结合本工程的具体情况， 甲、乙双方在平等、 自愿、协商一致的基础上达成如下协议，共同遵守。According to “ Contract Law” , and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect.1. 工

36、程概况Project overview工程名称：Project name:工程地点：Project location:工程范围：A. 新研发中心和新厂房的络综合布线系统的施工；B. 数据中心的建设， 主要包含： 数据中心的装饰工程、 电气系统、空调系统、机房闭路监控系统、机房门禁系统、 消防系统改造、机柜系统等。Project contents:A. The new R & D and new plant construction of network cabling systems;B. Data Center, mainly includes: data center decora

37、tion and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems.开工条件：合同生效后，甲方预付款到位和现场具备 开工条件。Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.工程造价：合同工程总造价

38、为YCNY ,人民币大写Project cost ： Total project cost is yuan ( CNY ).详细合同价格表见附件报价清单。Detailed contract price list see attached quotation list.在详细设计和施工过程中，若工程量发生变化，按合 同单价相应调整工程造价；若材质发生变化，按双方商定的 补充协议调整工程造价。In the detailed design and construction process, if the project quantity changes, according to the contr

39、act price adjustment project cost; if the material is changed, the supplemental agreement agreed by both parties for adjustment of engineering cost.2. 付款方式Terms of payment由乙方向甲方提供指定帐户、甲方以支票方式或银 行转账方式向乙方结算合同款； Party B shall provide the designated account to party A, Party A by check or bank transfer

40、to pay the contract payment to Party B.本合同生效后， 甲方付给乙方合同总价的40%作为工程预付款，即 Y元；After the signing of this contract,Party A shall pay to Party B 40% of the total contract price as the project advance payment;数据中心及络布线系统工程完工并且双方签订工程 验收报告后 7 天以内，甲方付给乙方合同总价的55%，即¥ 元；Data center project and network cabling

41、 systems engineering completed and signed a project acceptance report by both parties within 7 days after, Party A shall pay to Party B 55% of the contract price.工程竣工后 3 个月内，甲方支付给乙方剩余的合同 款，即¥After the completion of the project within 3 months, Party A shall pay to Party B the remaining contract

42、 price.3. 双方职责Responsibilities of the parties甲方职责：Responsibilities of party A:a. 及时以书面形式通知乙方本工程具备开工条件的 时间;Timely written notice to Party B the conditions of this project have the time to start;b. 协助乙方办理进驻施工现场所需人员证件、批件等 有关手续；To assist Party B to enter the construction site personnel required document

43、s, approval documents and other relevant procedures;c. 为乙方提供现场工程办公室和足够的现场仓库；To provide on-site engineering office and sufficient field warehouse;d. 积极协助乙方施工，协调施工时与各部门的配合， 并负责提供工程所需的现场平面图及建筑结构图。Actively assist Party B construction, coordination with various departments, and responsible for providing

44、the needed for the project site plans and architectural drawings.e. 及时按合同规定之付款进度向乙方支付工程款项。Timely according to the terms of the contract payment schedule to pay Party B project funds.乙方职责：Responsibilities of party B:a. 乙方在工程开始前应组织有关人员研究和熟悉图 纸，参与设计交底，安排施工总进度计划并提交给甲方；Party B before the project begins s

45、hall organize relevant personnel to study and be familiar with drawings, involved in the design work, arrangement of construction general schedule plan and submit to Party A;b. 向甲方或项目监理提供所购各种产品、设备的技 术资料，接受进场检验；To the party A or project supervision to provide the purchase a variety of products, equip

46、ment, technical information, accept entry inspection;c. 遵守甲方或监理方对施工现场的有关规定；Abide by the party or the supervision on construction site of the relevant provisions;d. 按时完成乙方所承担的施工任务，保证工程施工Timely completion of construction tasks undertaken by Party B, to ensure construction quality.4. 施工与工程设计变更Construct

47、ion and engineering design change乙方在施工中要根据国家颁发的施工验收规范和质 量检验标准，以及设计要求进行，要求全部工程达到合格标 准。On the construction of Party B according to the country issued construction acceptance norms and quality inspection standards, as well as the design requirements, all project achieve the qualified standard.在施工中，要坚持按

48、照设计文件和施工图纸施工，任 何一方不得随意变更设计，如出现窝工、返工和材料损失， 以及增加劳动力成本等，由于甲方的原因造成的，损失由甲 方承担，由于乙方的原因造成的，损失由乙方承担。During construction, to adhere to the design documents and construction drawings of the construction, any party shall not be arbitrarily changed design, such as the emergence of idleness, rework and loss of m

49、aterial, as well as an increase in labor cost, as the party A 's cause, loss borne by the party A, the Party B causes, losses shall be borne by Party B.在施工中，若甲方 A 有变更设计文件的要求，应书 面通知乙方；若乙方发现设计文件有错误或严重不合理的地 方，也应书面通知甲方，双方商定并修改设计文件和图纸后 方可继续施工。During the construction, if the party A to change the desi

50、gn document, shall give a written notice to Party B; if Party B is found the design documents are wrong or serious ueasonable place, should also be written notice to Party A, both sides agreed and modify design drawings and documents before it can continue to construction.在施工过程中，如遇下列情况，需顺延工期，双方 应及时进

51、行协商，并通过书面形式确定顺延期限：In the process of construction, in case of the following circumstances, be extended period, both parties shall timely consultations, and through the written form to determine the extension of the time limit:a. 因天灾或人力不能抗拒的原因被迫停工的；Because of natural disaster or the manpower irresisti

52、ble reasons forced shutdown;b. 因甲方提出变更计划或变更施工图而不能继续施工的；Because party A proposed changes to the plan or change the construction graph therefore cannot continue construction;c. 乙方不能按期供设备或所供材料或者设备不合规 格要求，被迫停工或不能顺利施工的；Party B fails tosupply equipment or for the materials or equipment of different specif

53、ications, was forced to shut down or not smooth construction;5. 竣工验收与售后服务Final acceptance and after-sales service 乙方必须严格执行隐蔽工程验收制度，凡隐蔽工程 完成后，必须经过验收并作好记录 ( 隐蔽工程指墙内、吊顶 内的管线施工等) 。Party B must strictly enforce the hidden work system, where the hidden work has been completed, must pass inspection and mak

54、e records (hidden works refers to the wall, the ceiling inside the pipeline construction, etc.).整体工程竣工后，乙方向甲方提交竣工文档并提交 书面验收申请。甲方接到申请后 7日内组织有关人员按照合同内容和事先约定的验收条款进行项目验收，并出具双方签字的验收报告。如甲方不能按期组织验收，须提前通知乙方，并与乙方另行商定验收日 期，但甲方必须承认乙方的竣工时间。甲方推迟验收，其间 所发生的管理费和各项损失均由甲方负担。如果提交验收申 请后一个月仍未能完成验收，则以竣工之日作为系统的保修 开始日期。 Wh

55、en the whole project is completed, Party B shall submit to party A complete documentation andsubmit a written acceptance application. Party A shallwithin 7 days after receivingthe applicationorganizerelevantpersonnel in accordance with the contractcontents and the prescribedinspectionclause ofprojec

56、tacceptance, and issue the report signed by both parties. If Party A fails to organize acceptance, shall inform Party B in advance, and Party B to be agreed date of acceptance, but party A must acknowledge party B completion time. party A delayed acceptance, during which occurred in the management f

57、ees and all losses shall be borne by Party A. If the submission of acceptance application one month after failed to complete acceptance, the completion date as the system warranty start date.工程验收合格后进入质保期。质保期为验收合格之 日起 12 个月。在质保期内，乙方应对系统除人为因素外的 所有故障负责免费维修或更换。Project after acceptance into the warranty

58、period. Warranty period from the date of acceptance of 12 months. During the warranty period, Party B shall system in addition to human factors all fault is responsible for free repair or replacement.在质保期内，乙方做到对甲方求援电话 2 小时内响 应， 8 小时内抵达现场并着手解决问题。质保期结束后，乙 方对系统进行有偿维护。有偿维护的费用由双方协商。During the warranty period, Party B shall do to help telephone response within 2 hours, 8 hours to arrive at the scene and set abou