《FIDIC课程设计》word版

1、 国际工程合同管理课程设计FIDIC 合同条件专用条款 姓名： 李飞班级： 10国工3学号：201022063指导教师： 韦嘉日期：2013.06.29Contents1. GENERAL PROVISIONS-1 1.1Definitions 1.5Priority of Documents 1.6Contract Agreement 1.8 Care and Supply of Documents 1.9 Supply of Documents 1.11 Delayed Drawings or Instructions 1.12 Confidential Details 1.13 Comp

2、liance with Laws 1.15 Details to be Confidential2. THE EMPLOYER -7 2.1 Right of Access to the Site 2.3 Employers Personnel 2.6 The Beneficiary3. THE ENGINEER-7 3.1 Engineers Duties and Authority 3.6 Management Meetings4. THE CONTRACTOR-9 4.1 Contractor's General Obligations 4.6 Cooperation 4.8 S

3、afety Procedures 4.9 Quality Assurance 4.10 Site Data 4.12 Unforeseeable Physical Conditions 4.14 Avoidance of the Interference 4.15 Access Route 4.17 Contractors Equipment 4.20 Employers equipment and free-issue material 4.21 Progress Report 4.24 Fossils 4.22 security of the site 4.24 Fossils 4.25

4、Works Diar 4.26 CONSTRUCTION LOG-BOOKS 4.27 Operation and maintenance manuals5. NOMINATED CONTRACTORS-156. STAFF AND LABOUR-16 6.1 Engagement of Staff and Labour 6.3 Persons in the Service of Employer 6.7 Health and safety 6.8 Contractor's Superintendence 6.9 Contractors Personnel 6.12 Foreign s

5、taff and labour 6.13 measures against insect and pest nuisance 6.15 Supply of water 6.14 alcoholic liquor or drugs7. PLANT, MATERIALS, AND WORKMANSHIP-19 7.1 Manner of Execution 7.9 Technical standards and Regulations8. COMMENCEMENT DELAYS AND SUSPENSION-20 8.1 Commencement of Work 8.4 Extension of

6、Time for Completion10 Employers taking over-21 10.2 Taking Over of Parts of the Works11 COMMENCEMENT, DELAYS AND SUSPENSION-2112. MEASUREMENT AND EVALUATION-21 12.2 Works to be Measured13. VARIATIONS AND ADJUSTMENTS-22 13.3 Variation Procedures 13.5 Provisional Sums14. CONTRACT PRICE AND PAYMENT-22

7、14.3 Application for Interim Payment Certificates 14.8 Delayed Payment 14.16 Audit and checks16 Suspension and Termination by Contractor-25 16.2 Termination by Contractor17 Risk and Responsibility- -25 17.7 Use of Employer's Accommodation/Facilities18 Insurance- -2620 claims , Dispute and Arbitr

8、ation- - - -26 20.4 Obtaining dispute adjudication boards decisionClause 1 General ProvisionsSub-Clause 1.1 DefinitionsIt may be necessary to delete some of the definitions and replaced . 1.1.1.1 “Contract” means the Form of Offer and Acceptance, Contract Data, these Conditions, the Specifications,

9、the Drawings, the Schedules, and the further documents (if any), which are listed in the Form of Offer and Acceptance, and further includes drawings and documents or parts thereof, which any of the aforesaid documents incorporate by reference.1.1.1.2 “Contract Agreement” means the document called Fo

10、rm of Offer and Acceptance.1.1.1.3 “Letter of Acceptance” means that section of the Form of Offer and Acceptance called Acceptance.1.1.1.4 “Letter of Tender” means that section of the Form of Offer and Acceptance called Offer.1.1.1.5 “Specification” means that document entitled Scope of Work, as inc

11、luded the Contract, and any additions and modifications to the Scope of Work in accordance with the Contract. Such document specifies the Works.1.1.1.7 “Schedules” means the document(s) entitled Tender Schedules, completed by the Contractor and submitted with his tender offer, as included in the Con

12、tract. Such document(s) may include the Bill of Quantities, data, lists and schedules of rates and / or prices.1.1.1.8 “Tender” means that section of the Form of Offer and Acceptance called Offer and all other documents which the Contractor submitted as Returnable Documents, as included in the Contr

13、act. 1.1.1.9 “Appendix to Tender” means the completed section entitled Appendix to Tender included in this Contract Data.Sub-Clause 1.1.3Add new Sub-Clause . 1.1.3.10 “Taking-Over Minutes upon Completion of Works” means the minutes issued and signed in accordance with the Applicable Laws by a taking

14、-over commission appointed by the Employer, at the Engineers request, recommending or not the taking-over of the Works, Section or part (as the case may be) by the Employer under Clause 10.”1.1.3.11 “Final Taking-Over Minutes” means the minutes issued and signed in accordance with the Applicable Law

15、s by a final taking over commission appointed by the Employer, at the Engineers request, recommending or not the final taking-over of the Works, Section or part (as the case may be) by the Employer under Sub-Clause 11.9.” Insert new Sub-Clause at the end of 1.1.4.121.1.4.13 “Unit Price” is the price

16、 of a unit quantity in the Bill of Quantitiesexcluding VAT.1.1.4.14 "Defect" includes any failure to comply with the requirements of the Technical Specifications or the Contractors Proposal or the Employers Requirements, or any other failure to comply with the provisions of the Contract or

17、 with the legal provisions regarding the quality of the Works.Sub-Clause 1.1.6.2Delete Sub Clause 1.1.6.2 and substitute with:“Country” means Spain.Sub-Clause 1.5 Priority of Documents Delete Sub-Clause 1.5 and substitute:“The documents forming the Contract are to be taken as mutuallyexplanatory of

18、one another. For the purposes of interpretation,the priority of the documents shall be in accordance with the following sequence:(a) the Contract Agreement,(b) the Letter of Tender,(c) the Particular Conditions,(d) these General Conditions,(e) the Specification,(f) the Drawings,(g) the Schedules, an

19、d(h) any other documents forming part of the Contract.Addenda and memoranda shall have the order of precedence ofthe documents they are modifying. If an ambiguity or discrepancy is found, the Engineer has authority to issue any instruction which he considers necessary to resolve an ambiguity or disc

20、repancy.Sub-Clause 1.6 - Contract AgreementDelete first sentence of Sub-Clause 1.6.Sub-clause1.8 Care and Supply of Documents Add：In addition to any other Contractors Documents necessary under the Contract，the Contractor is responsible for the preparation of Contractors Documents in the form of deta

21、iled construction drawings using AutoCAD software(working andor shop drawings) based on the Drawings for construction issued by the EngineerThis includes, if not otherwise specified, the preparation by the Contractor of all detailed concrete outline and detailed steel reinforcement drawings and bar

22、bending schedules to suit the Contractors Works；construction methodssequencing and temporary Project construction stages based on general concrete outline and steel reinforcement arrangement drawings(main steel reinforcement) issued by the Engineer The Contractor shall perform any required structura

23、l analysis related to temporary construction stages anticipated by him for the execution of works The Contractor shall prepare detailed drawings for excavations, embankmentsroads and architectural works and shall anticipate and be responsible for updating the Contractors Documents to incorporate： ch

24、anges to suit modifications arising from the encountered conditions revealed during construction, including instructions issued by the Engineer；drawing revisions issued by the Engineer andor other contractors required by me incorporation of the equipment and installations from the ME ContractsAll st

25、ructural steel works such as but not limited to the powerhouse roofincluding dome structures，roof structure of switchgear stationsteel beams for cranes, etc，shall be designed by the ContractorThe related structural calculations and shop drawings shall be prepared by the Contractor and submitted to t

26、he Engineer for approval This applies also to all metal works such as Iaddersstair cases, railingssteel gratings，checkered plates，steel doors and gates，etcThe Contractor is also responsible for the preparation and submission for approval of” asbuilt” drawings for the Works as constructed including f

27、ield changes.AIl such Contractors Documents shall be subject to the approval of the Engineer prior to commencement of work covered by the drawings and schedules. The Contractor shall promptly inform the Engineer if inadequate information can be obtained from the Drawings and the Contractor shall all

28、ow 56 days in his planning of the Works for approval by the Engineer of such Contractors Documents.1.9 Supply of DocumentsThe Specification and Drawings shall be in the custody and care of the Employer. Unless otherwise stated in the Contract, two copies of the Contract and of each subsequent Drawin

29、g shall be supplied to the Contractor, who may make or request further copies at the cost of the Contractor.Each of the Contractor's Documents shall be in the custody and care of the Contractor, unless and until taken over by the Employer. Unless otherwise stated in the Contract, the Contractor

30、shall supply to the Engineer six copies of each of the Contractor's Documents.The Contractor shall keep, on the Site, a copy of the Contract, publications named in the Specification, the Contractor's Documents (if any), the Drawings and Variations and other communications given under the Con

31、tract. The Employer's Personnel shall have the right of access to all these documents at all reasonable times.If a Party becomes aware of an error or defect of a technical nature in a document which was prepared for use in executing the Works, the Party shall promptly give notice to the other Pa

32、rty of such error or defect.1.9 Delayed Drawings or Instructions The Contractor shall give notice to the Engineer whenever the Works are likely to be delayed or disrupted if any necessary drawing or instruction is not issued to the Contractor within a particular time, which shall be reasonable. The

33、notice shall include details of the necessary drawing or instruction, details of why and by when it should be issued, and details of the nature and amount of the delay or disruption likely to be suffered if it is late.If the Contractor suffers delay and/or incurs Cost as a result of a failure of the

34、 Engineer to issue the notified drawing or instruction within a time which is reasonable and is specified in the notice with supporting details, the Contractor shall give a further notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 Contractor's Claims to:(a) an extension of

35、time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4 Extension of Time for Completion, and(b) payment of any such Cost plus reasonable profit, which shall be included in the Contract Price.After receiving this further notice, the Engineer shall proceed in accordance wit

36、h Sub¬ Clause 3.5 Determinations to agree or determine these matters.However, if and to the extent that the Engineer's failure was caused by any error or delay by the Contractor, including an error in, or delay in the submission of, any of the Contractor's Documents, the Contractor shal

37、l not be entitled to such extension of time, Cost or profit.Sub-Clause 1.13 - Compliance with LawsInsert at the end of this Sub-Clause 1.13:Applicable Laws of particular relevance for the Contract include,but are not limited to: Law No. Xxx.Insert at the end of sub-paragraph (b) of this Sub-Clause 1

38、.13:Except for the building permit to be provided by the Employer, authorisations and/or permits required from relevant national/local authorities shall be obtained by the Contractor, at his ownexpenses. Such permits include inter alia permits for site erection, traffic diversions, route permits, re

39、sidence and work permits, permits for radio communication, permits to relocate public utilities, etc. Within 21 days of the signature of the Contract Agreement, the Contractor shall submit to the Engineer the detailed planning of the Works, together with a list of all necessary permits with the time

40、 needed for obtaining those permits in order to properly carryout the Works in compliance with the programme prepared and updated under Sub-Clause 8.3 Programme.New Sub-Clause 1.15- Details to be ConfidentialInsert new Sub-Clause 1.15: The Contractor shall treat the details of the Contract Agreement

41、 as private and confidential, except to the extent necessary to carry out his obligations thereunder or to comply with applicable Laws. The Contractor shall not publish, permit to be published, or disclose any particulars of the Works in any trade or technical paper or elsewhere without the prior wr

42、itten agreement of the Employer.Clause 2 The EmployerSub-Clause 2.1 Right of Access to the siteIf right of access cannot be granted , both early and thereafter exclusively , details should be given in the Specification . Sub-Clause 2.3 Employers PersonnelThese provisions should be reflected in the E

43、mployers contracts with any other contractors on the site . Sub-Clause 2.6 the beneficiaryThe employer may assign any of his rights or duties under the contract to the beneficiaryThe beneficiary shall have no authority to amend the contract，to issue instructions under it, or to assign any part of th

44、e contract or any benefit or interest in or under it, except as may be agreed by and between the employer and the beneficiary.Whenever the employer takes over the works or a section or other part of the works under clause 1 0，such works，section or part are simultaneously transferred to the beneficia

45、rythe parties acknowledge that, for the purposes of considering any rights or obligations arising from the contract or works，the employer and the beneficiary are deemed to be the joint beneficiaries of the completed worksClause 3 The EngineerSub-Clause 3.1 - Engineer's Duties and AuthorityDelete

46、 paragraph 4 of this Sub-Clause 3.1 and substitute with:Except for cases when an emergency occurs, affecting the safety of life or of the Works or of adjoining property, and such emergency is expressly indicated within the document issued by the Engineer as an exercise of its specific authorities, w

47、henever the Engineer exercises such a specified authority for which the Employers approval is required as provided below, then, the Contractor shall not take any action if the document issued by the Engineer does not contain the express endorsement or approval of the Employer.In the first sentence o

48、f paragraph 5 of this Sub-Clause 3.1 delete “these conditions” and substitute with “the contract”Insert at the end of this Sub-Clause 3.1:The Engineer shall obtain the specific approval of the Employer before taking action under the following Sub-Clauses of these Conditions:a) Sub-Clause 4.4: Specif

49、ic approval of the Employer is requiredbefore issuing consent for any Sub-Contractor; (alternatively,this obligation could be limited to major Sub-Contractors, thatis those providing more than x% of the Accepted ContractAmount see Sub-Clause 4.4 Subcontractors)b) Sub-Clause 8.4 and/or Sub-Clause 13.

50、1: Specific approval ofthe Employer is required before instructing or approving anyextension of the Time for Completion Page 3 of 18c) Sub-Clause 13.1: Specific approval of the Employer isrequired before instructing or approving the omission of anyworkd) Sub-Clause 5.1 Subcontractors: giving consent

51、 to a Subcontractorfor works that should have been carried out by a different Sub-contractor named in the Contracte) Other cases, provided that the Contractor has been informedin this respect and in writing by the Employer with 30 daysnotice prior to the entering into force of such new case.Insert a

52、t the end of this Sub-Clause 3.1:Notwithstanding the obligation, as set out above, to obtain approval, if, in the opinion of the Engineer, an emergency occurs affecting the safety of life or of the Works or of adjoining property, he may, without relieving the Contractor of any of his duties and resp

53、onsibilities under the Contract, instruct the Contractor to execute all such work or to do all such things as may, in the opinion of the Engineer, be necessary to abate or reduce the risk. The Contractor shall forthwith comply with any such instruction of the Engineer. The Engineer shall determine a

54、n addition to the Contract Price, in respect of such instruction, in accordance with Sub-Clause 13.1 and shall notify the Contractor accordingly, with a copy to the Employer.3.1Engineer's Duties andThe Employer shall appoint the Engineer who shall carry out the duties assigned to Authorityhim in the Contract. The Enginee