建设工程委托监理合同（中英文）

精品文档2016全新精品资料全新公文范文全程指导写作独家原创1/47建设工程委托监理合同（中英文）CONTRACTREGISTRATIONNO_合同登记号SUPERVISIONCONTRACTFORCONSTRUCTIONPROJECT建设工程委托监理合同PROJECTNAME工程项目名称ENTRUSTORCLIENT委托方业主SERVICEPROVIDERSHANGHAITONGJIPROJECTMANAGEMENTSUPERVISORANDCONSULTINGCOLTD服务方监理人PLACEOFSIGNING签订地点DATEOFSIGNING签订时间VALIDPERIOD有效日期SHANGHAI,PRCHINA中国，上海XX年月日精品文档2016全新精品资料全新公文范文全程指导写作独家原创2/47SUPERVISIONCONTRACTFORCONSTRUCTIONPROJECT建设工程委托监理合同PARTIAGREEMENT第一部分建设工程委托监理合同THISAGREEMENTISSIGNEDBETWEENHEREINAFTERREFERREDTOAS“THECLIENT“ANDSHANGHAITONGJIPROJECTMANAGEMENTANDCONSULTINGCOLTDHEREINAFTERREFERREDTOASTHE“SUPERVISOR“THROUGHMUTUALCONSULTATION委托人与监理人经过双方协商一致,签订本合同IBRIEFINFORMATIONOFTHEPROJECTFORWHICHTHECLIENTDESIRESTHOSESUPERVISIONSERVICESSHOULDBEPERFORMEDBYTHESUPERVISORHEREINAFTERREFERREDTOAS“THEPROJECT“ISASFOLLOWS委托人委托监理人监理的工程以下简称“本工程“概况如下PROJECTNAME工程名称908新基地建设项目PROJECTLOCATION工程地点重庆北部黄茅坪组团经开园B04地块PROJECTSIZEABOUT185252M2精品文档2016全新精品资料全新公文范文全程指导写作独家原创3/47工程规模约185252M2TOTALINVESTMENTABOUTYUANRMB总投资约万元人民币IIINTHISAGREEMENTWORDSSHALLHAVETHESAMEMEANINGSASAREASSIGNEDTOTHEMINPARTIIOFTHISSUPERVISIONCONTRACTHEREINAFTERREFERREDTOAS“THECONTRACT”STANDARDCONDITIONS本合同的有关词语含义与本合同第二部分中赋予它们的定义相同IIITHEFOLLOWINGDOCUMENTSSHALLBEDEEMEDTOFORMPARTOFTHISAGREEMENT下列文件均为本合同的组成部分1THISAGREEMENT此协议书2STANDARDCONDITIONSOFTHECONTRACT本合同标准条件（条款）3CONDITIONSOFPARTICULARAPPLICATION本合同专用条件（条款）4SUPPLEMENTARYDOCUMENTSANDAMENDMENTSJOINTLYSIGNEDBYTHETWOPARTIESDURINGTHEEXECUTIONOFTHECONTRACT精品文档2016全新精品资料全新公文范文全程指导写作独家原创4/47在实施过程中双方共同签署的补充与修正文件监理人在报价时确定的的拟派现场监理人员名单和现场监理人员进场计划作为本合同附件。IVINCONSIDERATIONOFTHEPAYMENTTOBEMADEBYTHECLIENTTOTHESUPERVISORASHEREINAFTERMENTIONED,THESUPERVISORHEREBYCOVENANTSWITHTHECLIENTTOPERFORMSUPERVISIONSERVICESINTHESCOPEASSTATEDINTHECONDITIONSOFPARTICULARAPPLICATIONINCONFORMITYWITHTHEPROVISIONSOFTHECONTRACT考虑到以下提到的委托人向监理人的付款，监理人向委托人承诺,按照本合同的规定,承担本合同专用条件中议定范围内的监理业务VTHECLIENTHEREBYCOVENANTSTOPAYTHESUPERVISOR,INCONSIDERATIONOFTHEPERFORMANCEOFTHESUPERVISIONSERVICES,SUCHAMOUNTASMAYBECOMEPAYABLEUNDERTHEPROVISIONSOFTHECONTRACTATTHETIMESANDINTHEMANNERANDCURRENCYTYPEPRESCRIBEDBYTHECONTRACT考虑到监理人提供的监理服务，委托人向监理人承诺按照本合同注明的期限,方式,币种,向监理人支付报酬INWITNESSWHEREOFTHEPARTIESHERETOHAVECAUSED精品文档2016全新精品资料全新公文范文全程指导写作独家原创5/47THISAGREEMENTTOBEEXECUTEDFROMAPRIL,XXTOOCTOBER,XXIFFORANYREASONSTHEPROJECTSTOPSFORMORETHANONEMONTHUNINTERRUPTED,THEENDINGDATEWILLBEPOSTPONEDWITHSAMEPERIODS本合同自施工单位进场时开始,至整个工程竣工验收止完成如果项目进行中，被停止连续时间超过一个月，完成时间应该被顺延。THISAGREEMENTHASSIXSETSOFORIGINALCOPIES,THEYHAVETHESAMELEGALEFFECT,ANDEACHPARTYSHALLHOLDTHREECOPIES本合同一式陆份,具有同等法律效力,双方各执叁份THECLIENT委托人SEAL签章THESUPERVISORSHANGHAITONGJIPROJECTMANAGEMENTANDCONSULTINGCOLTD监理人SEAL签章ADDRESS住所精品文档2016全新精品资料全新公文范文全程指导写作独家原创6/47ADDRESS73CHIFENGROADSHANGHAI,XX92住所上海市赤峰路73号,XX92LEGALREPRESENTATIVESIGNATURE法定代表人签章LEGALREPRESENTATIVESIGNATURE法定代表人签章PRINCIPALBANK开户银行PRINCIPALBANK开户银行交行赤峰路支行BANKACCOUNTNO1001721509300007736帐号BANKACCOUNTNO帐号310066344010141052919TEL电话TEL862165989931电话862165989931THISCONTRACTISSIGNEDON,XX本合同签订于XX年月日精品文档2016全新精品资料全新公文范文全程指导写作独家原创7/47PARTIISTANDARDCONDITIONS第二部分标准条件DEFINITIONS,APPLICABLELANGUAGESANDLAWS词语定义,适用语言和法规ARTICLE1THEFOLLOWINGWORDSANDEXPRESSIONSSHALLHAVETHEMEANINGSASSIGNEDTOTHEMEXCEPTWHERETHECONTEXTOTHERWISEREQUIRES第一条下列名词和用语，除上下文另有规定外，具有如下所赋予的含义1“PROJECT“MEANSTHEPROJECTFORWHICHTHESUPERVISIONSERVICESARETOBEPROVIDED“工程“是指实施委托人委托监理人监理的工程。2“CLIENT“MEANSTHEPARTYWHOISRESPONSIBLEFORTHEDIRECTINVESTMENTANDWHOEMPLOYSTHESUPERVISOR,ANDLEGALSUCCESSORSTOTHECLIENT“委托人“是指承担直接投资责任和委托监理人的一方,以及其合法继承人。3“SUPERVISOR“MEANSTHEPARTYWHOISEMPLOYEDBYTHECLIENTTOPERFORMSUPERVISIONSERVICESANDASSUMESUPERVISIONLIABILITIES,ANDLEGALSUCCESSORSTOTHESUPERVISOR“监理人“是指受委托人委托承担监理业务和监理责任的一精品文档2016全新精品资料全新公文范文全程指导写作独家原创8/47方,以及其合法继承人4“SUPERVISIONTEAM“MEANSTHEGROUPOFSTAFFSENTBYTHESUPERVISORTOCARRYOUTSUPERVISIONONTHESITEOFTHEPROJECT“监理机构“是指监理人派驻本工程现场实施监理业务的组织5“CHIEFSUPERVISIONENGINEER“MEANSTHEPERSONCERTIFICATEDBYTHELOCALAUTHORITYASCHIEFSUPERVISIONENGINEERANDDESIGNATEDBYTHECLIENTANDSUPERVISORTOBEFULLYRESPONSIBLEFORSUPERVISINGTHEEXECUTIONOFTHECONTRACT“总监理工程师“是指经当地政府部门认证为的总监理工程师并且由委托人及监理人指定对监督履行本合同全权负责的人6“CONTRACTOR“MEANSTHEPERSONSOTHERTHANTHESUPERVISORWITHWHOMTHECLIENTSIGNSCONTRACTINRELATIONTOTHECONSTRUCTIONOFTHEPROJECT“承包人“是指除监理人以外,委托人就本工程的建设有关事宜签订合同的当事人7“NORMALSERVICES“MEANSTHESCOPEOFSUPERVISIONWORKPRESCRIBEDINTHECONDITIONSOFPARTICULARAPPLICATION精品文档2016全新精品资料全新公文范文全程指导写作独家原创9/47“正常工作“是指双方在专用条件中约定的监理工作的范围8“ADDITIONALSERVICES“MEANS1WORKSOUTSIDEOFTHESCOPEOFSUPERVISIONWORK,ANDADDEDTOTHECONTRACTBYWRITTENAGREEMENTOFTHEPARTIES2ADDITIONALWORKSASARESULTOFADDITIONTOTHESCOPEOFCONSTRUCTIONWORKORPROGRAMDELAYONTHEPARTOFTHECLIENTORTHECONTRACTOR“附加工作“是指1监理工作范围以外,通过双方书面协议另外增如本合同的工作2建设工作范围的增加或者由于委托人或承包人原因致使进度的延误,而造成的附加的工作9“EXCEPTIONALSERVICES“MEANSTHEWORKSOTHERTHANTHENORMALSERVICESANDTHEADDITIONALSERVICES,BUTWHICHARENECESSARILYPERFORMEDBYTHESUPERVISORINACCORDANCEWITHARTICLE33“额外工作“是指正常工作和附加工作以外，根据第三十三条规定监理人需要完成的工作。10“DAY“MEANSTHEPERIODBETWEENANYONE000ANDTHENEXT“日“是指任何一个零时至第二天零时的时间段11“MONTH“MEANSAPERIODOFONEMONTHACCORDINGTOTHEGREGORIANCALENDARCOMMENCINGWITHANYDAYOFTHEMONTH“月“是指精品文档2016全新精品资料全新公文范文全程指导写作独家原创10/47根据公历从一个月份中任何一天开始的一个月的时间段ARTICLE2THISSUPERVISIONCONTRACTSHALLBEGOVERNEDBYCHINESELAWS,STATUTES,ADMINISTRATIVEREGULATIONS,ANDDEPARTMENTALRULESPROVIDETOTHECLIENTANAMELISTOFTHECHIEFSUPERVISIONENGINEER,MAINSTAFFOFTHESUPERVISIONTEAMANDASUPERVISIONPLANANDPERFORMTHESUPERVISION精品文档2016全新精品资料全新公文范文全程指导写作独家原创11/47SERVICESWITHINTHESCOPEOFWORKASSTATEDINTHECONDITIONSOFPARTICULARTHEEXECUTIONOFTHECONTRACT,THESUPERVISORSHALLSUBMITSUPERVISIONREPORTTOTHECLIENTATREGULARINTERVALASSTATEDINTHECONTRACT第四条监理人应派出监理工作需要的监理机构及监理人员，向委托人报送委派的总监理工程师及其监理机构主要成员名单，监理规划，完成监理合同专用条件中约定的监理工程范围内的监理业务。在履行本合同义务期间，应按合同约定定期向委托人报告监理工作。ARTICLE5THESUPERVISORSHALLEXERCISEREASONABLECAREANDDILIGENCE,PROVIDEADVICEATANAPPROPRIATELEVELINTHEPERFORMANCEOFTHEOBLIGATIONSUNDERTHECONTRACTTOTHECLIENTANDINDEMNIFYTHELAWFULRIGHTSANDINTERESTSOFVARIOUSPARTIES第五条监理人应认真，勤奋地工作，在履行合同义务时为委托人提供与其水平相应的咨询意见，公正维护各方的合法权益。ARTICLE6ANYFACILITIESANDARTICLESSUPPLIEDBYTHECLIENTFORUSEBYTHESUPERVISORSHALLBEPROPERLYUSEDANDMAINTAINEDANDREMAINTHEPROPERTYTOTHECLIENTWHENTHESERVICESARECOMPLETED精品文档2016全新精品资料全新公文范文全程指导写作独家原创12/47ORTERMINATEDTHESUPERVISORSHALLDELIVERTOTHECLIENTSUCHFACILITIESANDUNCONSUMEDARTICLESINGOODWORKINGORDER第六条监理人使用委托人提供的设施和物品属委托人的财产，应恰当使用和维护。在监理工作完成或中止时，应将其设施和剩余的物品完好地移交给委托人。ARTICLE7DURINGTHECONTRACTPERIODORAFTERTHECONTRACTISTERMINATED,WITHOUTTHECONSENTOFTHECLIENT,THESUPERVISORSHALLNOTDISCLOSETHECONFIDENTIALINFORMATIONINRELATIONTOTHEPROJECTANDTHECONTRACT第七条合同期内或本合同终止后，未征得委托人同意，不得泄露与本工程和本合同有关的保密信息。OBLIGATIONSOFTHECLIENT委托人的义务ARTICLE8THECLIENTSHALLPAYANADVANCEPAYMENTTOTHESUPERVISORPRIORTOTHECOMMENCEMENTOFTHESERVICESOFTHESUPERVISOR,IFSUCHADVANCEPAYMENTISSTATEDINTHECONDITIONSOFPARTICULARAPPLICATION第八条委托人在监理人开展监理业务之前应向监理人支付预付款,如果该预付款在专用条件中陈述。精品文档2016全新精品资料全新公文范文全程指导写作独家原创13/47ARTICLE9THECLIENTSHALLBERESPONSIBLEFORALLCOORDINATIONOFEXTERNALRELATIONSHIPSINRELATIONTOTHECONSTRUCTIONOFTHEPROJECTIFTHECLIENTASSIGNSPARTORALLOFSUCHCOORDINATIONWORKSTOTHESUPERVISORASISNECESSARY,THENTHEWORKTOBEASSIGNEDANDRELEVANTTERMSOFREMUNERATIONSHALLBESPECIFIEDINTHESUPPLEMENTALCLAUSES第九条委托人应当负责本工程建设的所有外部关系的协调（监理人所属协调关系除外）。根据需要，如需将部分或全部协调工作委托监理人承担，则需在补充条款中明确委托的工作和相应的报酬条款。ARTICLE10THECLIENTSHALL,WITHINTHEAGREEDTIME,PROVIDETOTHESUPERVISORFREEOFCHARGEALLINFORMATIONPERTAININGTOTHEPROJECTANDNECESSARYFORTHESUPERVISIONSERVICES第十条委托人应当在双方约定的时间内免费向监理人提供与本工程有关的并为监理工作需要的所有信息。ARTICLE11ONALLMATTERSPROPERLYREFERREDTOHIMINWRITINGBYTHESUPERVISOR,THECLIENTSHALLGIVEHISDECISIONINWRITINGWITHINTHETIMESPECIFIEDINTHECONDITIONSOFPARTICULARAPPLICATIONOFTHE精品文档2016全新精品资料全新公文范文全程指导写作独家原创14/47CONTRACT第十一条委托人应当在专用条件约定的时间内就监理人向委托人以恰当的书面形式提交的一切事宜作出书面决定。ARTICLE12THECLIENTSHALLAPPOINTACLIENTSREPRESENTATIVETOBESPECIFIEDINTHECONDITIONSOFPARTICULARAPPLICATIONWHOISFAMILIARWITHTHEPROJECTANDABLETOMAKEDECISIONWITHINSPECIFIEDTIMEFORTHEPURPOSEOFCONTACTINGTHESUPERVISORSHOULDTHECLIENTSREPRESENTATIVEBEREPLACED,THECLIENTSHALLNOTIFYTHESUPERVISORINADVANCE第十二条委托人应当授权一名熟悉本工程情况，能在规定时间内作出决定的委托人的代表将在专用条件中明确负责与监理人联系，更换委托人代表要提前通知监理人。ARTICLE13THECLIENTSHALLTIMELYNOTIFYTHEAWARDEDCONTRACTOR,INWRITING,OFTHEPOWEROFTHESUPERVISOR,ROLESANDAUTHORITIESOFMAINSTAFFOFTHESUPERVISORSUCHINFORMATIONSHALLBEMADECLEARINTHECONTRACTSIGNEDBYTHECLIENTANDANYTHIRDPARTY第十三条委托人应当将授予监理人的监理权利，以及监理人主要成员的职能分工及监理权限及时书面通知已选定的合同承包商，并在与任何第三方签订的合同中予以明确。精品文档2016全新精品资料全新公文范文全程指导写作独家原创15/47ARTICLE14THECLIENTSHALLNOTIFYTOCONTRACTORTOPROVIDETHEFOLLOWINGINFORMATIONTOTHESUPERVISORWITHINSUCHATIMETHATTHESUPERVISORSWORKWILLNOTBEHAMPERED第十四条委托人应通知承包人在不影响监理人开展监理工作的时间内向监理人提供如下资料1LISTOFSUPPLIERS与将用于本工程的原材料，构配件，机械设备等的供应和生产厂家名录；2LISTOFCOORDINATORS,COOPERATORSINRELATIONTOTHEDEVELOPMENTOFTHEPROJECT提供与本工程有关的协作人，配合人的名录。ARTICLE15THECLIENTSHALLFURNISHFREEOFCHARGEINCLUDINGUTILITYFEESTOTHESUPERVISORTHESITEOFFICE,TELECOMMUNICATIONCONNECTION,ACCOMMODATIONANDOTHERFACILITIESSPECIFIEDINTHECONDITIONSOFPARTICULARAPPLICATION第十五条委托人应免费（包括使用费）向监理人提供办公场所、通讯接口，网路接口住宿及合同专用条件约定的其他设施。精品文档2016全新精品资料全新公文范文全程指导写作独家原创16/47ARTICLE16GIVENCERTAINCIRCUMSTANCES,IFTHETWOPARTIESAGREETHATTHECLIENTSHALLARRANGEATHISOWNEXPENSEFORTHEPROVISIONOFOTHERPERSONNELTOTHESUPERVISOR,SUCHAGREEMENTSHALLBEREFLECTEDINTHECONDITIONSOFPARTICULARAPPLICATION第十六条根据情况需要，如经双方同意委托人将可以自费向监理人提供其他人员，应在合同专用条件中予以反映。RIGHTSOFTHESUPERVISOR监理人的权利ARTICLE17THESUPERVISORSHOULDHAVETHEFOLLOWINGRIGHTSWITHINHISSCOPEOFWORKITISHEREBYUNDERSTOODTHATANYANDALLOFTHEFOLLOWINGACTIVITIESSHALLALSOBECONSIDEREDASTHEOBLIGATIONOFTHESUPERVISOR,WHOSHALLPERFORMTHEFOLLOWINGACTIVITIESWHENEVERITISNEEDEDINORDERTOENSURECOMPLETIONOFTHEPROJECTINTHEBESTPOSSIBLEMANNERANDACCORDINGTOTHERELEVANTCONTRACTUALDOCUMENTSANDAPPLICABLELAWS第十七条监理人在委托的工程范围内应具有以下权利，而且在此双方确认任何如下活动也应作为监理人的义务，即其有义务在有必要的情况下为了以最好的方式并以符合全部合同文件和适用的法律的方式完成本项目的目的而进精品文档2016全新精品资料全新公文范文全程指导写作独家原创17/47行如下活动。1THERIGHTANDOBLIGATIONTOMAKERECOMMENDATIONSONTHESELECTIONOFTHEGENERALCONTRACTOR1选择工程总承包人的建议权和义务；2THERIGHTANDOBLIGATIONTOMAKERECOMMENDATIONSONTHESELECTIONOFTHESUBCONTRACTOR2选择工程分包人的建议权和义务；3THERIGHTANDOBLIGATIONTOMAKERECOMMENDATIONSTOTHECLIENTINTHERESPECTSOFTHEPROJECTINCLUDINGPROJECTSIZE,DESIGNSTANDARD,PLANNINGDESIGN,TECHNOLOGICALDESIGNANDPERFORMANCEREQUIREMENTS3对工程建设有关事项包括工程规模、设计标准、规划设计、生产工艺设计和使用功能要求，向委托人的建议权和义务；4THERIGHTANDOBLIGATIONTOADVISE,INTHEPRINCIPLESOFSAFETYANDOPTIMUM,THECLIENTONTHETECHNICALPROBLEMSINTHEDESIGNIFTHEDESIGNISFOUNDTOBENOTINCONFORMITYWITHTHEQUALITYSTANDARDSPROMULGATEDBYTHESTATEORSPECIFIEDINTHEDESIGNCONTRACT,THESUPERVISORSHALLREPORTTOTHECLIENTINWRITING精品文档2016全新精品资料全新公文范文全程指导写作独家原创18/474对工程设计中的技术问题,按照安全和最优化的原则,有权利和义务向委托人提出建议当发现工程设计不符合国家颁布的建设工程质量标准或设计合同约定的质量标准时,监理人应当书面报告委托人并提供处理方案5THERIGHTANDOBLIGATIONTOREVIEWTHECONSTRUCTIONMANAGEMENTPLANANDTHETECHNICALPROPOSALANDTOMAKERECOMMENDATIONTOTHECLIENTFORCHANGESTHATTHECONTRACTORCOULDIMPLEMENTTOENSUREQUALITY,ONTIMECOMPLETIONANDCOSTREDUCTION5对审查工程施工组织和技术方案,按照保质量、保工期和降低成本的原则,并就承包人有可能采取的变化监理人有权利和义务向委托人提出建议并提供处理意见6CONDUCTAPPROPRIATEARRANGEMENTANDCOORDINATIONWITHRELEVANTORGANISATIONS,WHICHCANEXERTBENEFICIALINFLUENCETOTHEDEVELOPMENTOFTHEPROJECTFORALLSUCHMATTERSTHESUPERVISORSHALLFIRSTREPORTTOTHECLIENTINADVANCEANDSEEKTHEAUTHORITYOFTHECLIENTTOMAKESUCHARRANGEMENTSANDCOORDINATION6主持工程建设有关协作单位的组织协调,对于所有协调项应当事先向委托人报告,并要求委托人授权以进行组织协精品文档2016全新精品资料全新公文范文全程指导写作独家原创19/47调工作7HAVINGOBTAINEDTHECONSENTOFTHECLIENT,THESUPERVISORHASTHERIGHTTOGIVECOMMANDWITHREGARDSTOCOMMENCEMENT,SUSPENSIONANDRESUMPTIONOFTHEWORKSBUTBEFOREDOINGSO,HESHALLREPORTTOTHECLIENTTHECLIENTSREPRESENTATIVEWILLBEAVAILABLEFORCONTACTINGINPHONETODISCUSSEMERGENCYANDOTHERMATTERS7征得委托人同意,监理人有权发布开工令,停工令,复工令,但应当事先向委托人作出书面报告委托人代表将可以随时电话联系到以就紧急情况和其他事宜与监理人进行研究8RIGHTANDOBLIGATIONTOCHECKANDINSPECTTHEMATERIALSTOBEUSEDINTHEPROJECTANDQUALITYOFCONSTRUCTIONANDTOADVISETHECONTRACTORIMMEDIATELYOFANYNONCONFORMITIESSHOULDTHECONTRACTORCONTINUETOUSETHEMATERIALSAFTERTHENONCONFORMITYHASBEENIDENTIFIED,THENTHESUPERVISORMUSTADVISETHECLIENTTHATTHECONTRACTORSHOULDSTOPUSINGTHEMFORMATERIALS,COMPONENTSANDPARTS,EQUIPMENTTHATARENOTINCONFORMITYWITHTHEDESIGNREQUIREMENTS,PROVISIONS精品文档2016全新精品资料全新公文范文全程指导写作独家原创20/47OFTHECONSTRUCTIONCONTRACTANDNATIONALQUALITYSTANDARDS,THESUPERVISORHASTHERIGHTTONOTIFYTHECLIENTTHATTHECONTRACTORSHOULDSTOPUSINGTHEMFORWORKINGSEQUENCE,DIVISIONALANDSUBDIVISIONALWORKSTHATARENOTINCONFORMITYWITHRELEVANTCODESANDQUALITYSTANDARDS,ANDCONSTRUCTIONOPERATIONSTHATPOSESAFETYCONCERNS,THESUPERVISORHASTHERIGHTTONOTIFYTHECLIENTTHATTHECONTRACTORSHOULDSTOPANDMAKECORRECTIONSORREDOTHECONTRACTORCANRESUMECONSTRUCTIONONLYAFTERHEHASRECEIVEDTHEWORKRESUMPTIONCOMMANDFROMTHESUPERVISIONTEAMVIATHECLIENT8工程上使用的材料和施工质量的检验权和义务发现不合格材料应通知承包方，如果承包人在接到通知后仍继续使用该不合格材料,监理人必须及时通知委托人,让承包人不得继续使用对于不符合设计要求和合同约定及国家质量标准的材料,构配件,设备,监理人有义务通知委托人让承包人停止使用对于不符合规范和质量标准的工序,分部分项工程和不安全的施工作业,监理人有义务及时通知委托人，监理人有权让承包人停工整改,返工承包人只有通过委托人收到监理机构发出复工令后才能复工精品文档2016全新精品资料全新公文范文全程指导写作独家原创21/479RIGHTSANDOBLIGATIONTOCHECK,SUPERVISETHEPROGRESSOFTHECONSTRUCTIONRIGHTTORATIFYTHATTHEACTUALCOMPLETIONISAHEADORBEHINDTHECOMPLETIONDATESPECIFIEDINTHECONSTRUCTIONCONTRACT9工程施工进度的检查、监督权和义务，以及工程实际竣工日期提前或超过工程施工合同规定的竣工期限的签认权和义务；10RIGHTANDOBLIGATIONTOCHECKANDCERTIFYBYSIGNATURETHATTHEPAYMENTTOTHECONSTRUCTIONCONTRACTORISWITHINTHESCOPEOFTHECONSTRUCTIONCONTRACT,TORECHECK,CONFIRM,ANDNEGATETOTHESETTLEMENTOFTHEACCOUNTSWITHOUTTHESIGNATUREANDCONFIRMATIONFROMTHECHIEFSUPERVISIONENGINEER,THECLIENTWILLNOTMAKEPAYMENTTOTHECONSTRUCTIONCONTRACTOR10在工程施工合同约定的工程价格范围内，工程款支付的审核和签认权和义务，以及工程结算的复核确认权与否定权。未经总监理工程师签字确认，委托人不支付工程款。ARTICLE18DURINGSUPERVISION,IFTHEEMPLOYEESOFTHECONTRACTORISFOUNDTOBEINCAPABLEOFHISJOB,精品文档2016全新精品资料全新公文范文全程指导写作独家原创22/47THESUPERVISIONTEAMSHALLNOTIFYTHECLIENTOFTHEVIEWSOFTHESUPERVISIONTEAMONTHISMATTER第十八条在监理过程中如发现工程承包人员工作不力,监理机构应将其对此事的观点告知委托人ARTICLE19WITHINTHESCOPEOFWORK,IFTHECLIENTANDTHECONTRACTORHAVEANYDISSENTANDREQUIREMENTINCLUDINGCLAIMTOEACHOTHER,ANDWHERESUCHDISPUTEISBEINGMEDIATEDBYANADMINISTRATIVEDEPARTMENTINCHARGEOFCONSTRUCTIONORBEINGARBITRATEDBYARBITRATIONBODYCHINAINTERNATIONALECONOMICANDTRADEARBITRATIONCOMMISSION,SHANGHAI,THESUPERVISORSHALLPROVIDERELEVANTPROOF第十九条在委托的工程范围内，当委托人和承包人对对方有任何意见和要求包括索赔要求,双方争议由政府建设行政主管部门调解或仲裁机关（中国国际经济贸易仲裁委员会上海H1）仲裁时，监理人应当提供相关证明。RIGHTSOFTHECLIENT委托人的权利ARTICLE20THECLIENTHASTHERIGHTTOAPPOINTTHECONTRACTORANDENTERINTOACONTRACTWITHTHATCONTRACTOR精品文档2016全新精品资料全新公文范文全程指导写作独家原创23/47第二十条委托人有选定工程承包人，以及与其签订合同的权利。ARTICLE21THECLIENTHASTHERIGHTTODECIDETHEPROJECTSIZEANDAGREETHEDESIGNSTANDARD,PLANNINGDESIGN,TECHNOLOGICALDESIGNANDDESIGNEDPERFORMANCEREQUIREMENTSANDTHERIGHTTOAPPROVECONSTRUCTIONCOST,PROGRAMMEANDDESIGNVARIATION第二十一条委托人享有对工程规模、设计标准，规划设计、生产工艺设计和设计使用功能要求的认定权，以及对工程造价、进度计划和设计变更的审批权。ARTICLE22INTHEEVENTTHATTHESUPERVISORWANTTOREPLACETHECHIEFSUPERVISIONENGINEER,HESHALLOBTAINTHECLIENTSCONSENTINADVANCEDURINGTHECONTRACTCONDUCTINGPERIOD第二十二条在履行本合同期间,监理人调换总监理工程师须事先经委托人同意。ARTICLE23THECLIENTHASTHERIGHTTOREQUIRETHESUPERVISORTOSUBMITSUPERVISIONREPORTANDSPECIFICREPORTINEACHDISCIPLINEWITHINTHESUPERVISORSSCOPEOFWORK第二十三条委托人有权要求监理人提交监理工作报告及监精品文档2016全新精品资料全新公文范文全程指导写作独家原创24/47理人业务范围内的专项报告。ARTICLE24INTHEEVENTTHATTHECLIENTFINDTHESUPERVISORSSTAFFFAILSTOPERFORMDUTIESUNDERTHECONTRACT,ORCAUSEANYLOSSTOTHEPROJECTORTHECLIENTTHROUGHCOLLUSIONWITHTHECONTRACTOR,THECLIENTSHALLBEENTITLEDTOREQUIRETHATSUCHSTAFFBEREPLACEDBYTHESUPERVISOROREVENTERMINATETHECONTRACTANDDEMANDTHESUPERVISORTOASSUMERESPONSIBILITIESORCONTIGUOUSRESPONSIBILITIESINPAYINGCOMPENSATION第二十四条当委托人发现监理人的职员不按本合同履行监理职责，或与承包人串通给本工程或委托人造成任何损失的，委托人有权要求监理人更换该职员，直到终止合同并要求监理人承担相应的赔偿责任或连带赔偿责任。LIABILITIESOFTHESUPERVISOR监理人的责任ARTICLE25THESUPERVISORSLIABILITYPERIODISTHEVALIDPERIODOFTHECONTRACTCONTRACTPERIOD,INCLUDINGTHEMAINTENANCEPERIODINTHEEVENTTHATTHEPROJECTPROGRAMMEISPOSTPONEDORDELAYWHICHRESULTSINTHECONTRACTPERIODTOBEEXTENDED,THETWOPARTIESSHALLMAKEFURTHERNEGOTIATIONTOAGREEANEXTENSIONOFTHECONTRACTPERIOD精品文档2016全新精品资料全新公文范文全程指导写作独家原创25/47第二十五条监理人的责任期即本合同有效期（合同期），包括维护期。如果因工程进度的推迟或延误而导致合同期将要延长，双方应进一步协商约定的延长合同期。ARTICLE26THESUPERVISORSHALLPERFORMHISDUTIESDURINGTHECONTRACTPERIODSHOULDANYFINANCIALLOSSBECAUSEDBYTHEFAULTOFTHESUPERVISOR,HESHALLPAYCOMPENSATIONTOTHECLIENTACCUMULATEDAMOUNTOFCOMPENSATIONEXCEPTFORTHECOMPENSATIONSPECIFIEDINARTICLE24SHALLNOTEXCEEDTHETOTALPAYMENTBYTHECLIENTTOTHESUPERVISOREXCLUDINGINCOMETAX第二十六条监理人在合同期内，应当履行约定的责任。如果因监理人过失而造成了委托人的任何经济损失，其应当向委托人赔偿。累计赔偿总额（除第二十四条规定的赔偿以外）不应超过委托人向监理人支付的报酬总数（除去税金）。赔偿按相关法律执行H2ARTICLE27THESUPERVISORSHALLBENOTRESPONSIBLEFORANYCONTRACTORSNONCONFORMITYINQUALITYREQUIREMENTSANDCOMPLETIONTIMEFORSUBMITTINGDRAWINGSORDELIVERYOFGOODSINTHEEVENTOFANYFORCEMAJEUREWHICHCAUSEPARTORALLOFTHEEXECUTIONOFTHECONTRACTTOBEIMPOSSIBLE,THE精品文档2016全新精品资料全新公文范文全程指导写作独家原创26/47SUPERVISORSHALLNOTBEHELDRESPONSIBLEBUTFORANYINFRINGEMENTTOARTICLE5,THESUPERVISORSHALLPAYCOMPENSATIONTOTHECLIENT第二十七条监理人对承包人违反施工合同规定的质量要求和完工交图、交货时限，因监理人失责应承担相应的责任，因不可抗力导致本合同不能全部或部分履行，监理人不承担责任。但对违反第五条规定引起的与之有关的事宜，应向委托人承担赔偿责任。ARTICLE28IFTHECLAIMMADEBYTHESUPERVISORTOTHECLIENTCANNOTBEJUSTIFIED,THESUPERVISORSHALLBERESPONSIBLEFORANYCOSTINCURREDBYTHECLIENTINRELATIONTOTHECLAIM第二十八条监理人向委托人提出赔偿要求不能成立时，监理人应当补偿由于该索赔所导致委托人的任何费用支出。LIABILITIESOFTHECLIENT委托人的责任ARTICLE29THECLIENTSHALLCARRYOUTHISDUTIESASSTATEDINTHECONTRACTTHECLIENTSHALLBELIABLETOTHESUPERVISORIFABREACHOFHISDUTYTOTHESUPERVISORISESTABLISHEDAGAINSTTHECLIENT,ANDSHALLPAYCOMPENSATIONFORTHESUPERVISORSDIRECTFINANCIALLOSS第二十九条委托人应当履行本合同约定的义务，如有违反精品文档2016全新精品资料全新公文范文全程指导写作独家原创27/47则应当承担违约责任，赔偿给监理人造成的直接经济损失。ARTICLE30IFTHECLAIMMADEBYTHECLIENTTOTHESUPERVISORCANNOTBEJUSTIFIED,THECLIENTSHALLBERESPONSIBLEFORANYCOSTINCURREDBYTHESUPERVISORINRELATIONTOTHECLAIM第三十条委托人如果向监理人提出赔偿的要求不能成立，则应当补偿由该索赔所引起的监理人的各种费用支出。COMMENCEMENT,ALTERATIONANDTERMINATIONOFTHECONTRACT本合同的开始、变更与终止ARTICLE31IFTHENORMALSERVICESAREIMPEDEDORDELAYEDBYTHECLIENTORTHECONTRACTORSOASTOINCURADDITIONALSERVICESORINCREASETHEDURATIONOFTHENORMALSERVICES,THESUPERVISORSHALLTIMELYINFORMTHECLIENTOFTHECIRCUMSTANCESANDPROBABLEEFFECTSTHETIMEFORCOMPLETIONOFTHESERVICESSHALLBEINCREASEDACCORDINGLYANDTHESUPERVISORSHALLBEREMUNERATEDFORSUCHADDITIONALSERVICES第三十一条由于委托人或承包人的原因使正常的监理工作受到阻碍或延误，以致发生了附加工作或延长了正常监理工作的持续时间，则监理人应当将此情况与可能产生的影响及时通知委托人。完成监理业务的时间相应延长，并得精品文档2016全新精品资料全新公文范文全程指导写作独家原创28/47到附加工作报酬。ARTICLE32IFCIRCUMSTANCESARISEWHICHMAKEITLEGALLYORPHYSICALLYIMPOSSIBLEFORTHESUPERVISORTOPERFORMINWHOLEORINPARTTH