合同范本之刮瓷施工合同(2024版)

合同范本之刮瓷施工合同(2024版)GypsumPlasteringConstructionContract(2024Edition)ContractNo.:_______DateofContract:_______PartyA(Client):_______Address:_______LegalRepresentative:_______ContactNumber:_______PartyB(Contractor):_______Address:_______LegalRepresentative:_______ContactNumber:_______Article1PurposeoftheContractThiscontractisestablishedtodefinethetermsandconditionsofthegypsumplasteringconstructionservicesprovidedbyPartyBtoPartyA,ensuringthequalityandtimelinessoftheconstructionwork.Article2ProjectOverviewProjectName:_______ProjectLocation:_______ScopeofWork:Theprojectinvolvesgypsumplasteringfortheinteriorwallsandceilingsofthe_______(specifyareaorbuilding).Article3ContractPriceandPaymentTermsThetotalcontractpriceforthegypsumplasteringworkis_______RMB.PartyAshallmakethepaymentsaccordingtothefollowingschedule:Adepositof_______%ofthetotalcontractpriceuponsigningthiscontract._______%uponcompletionofthework,subjecttoPartyA'sinspectionandacceptance.Thefinalpaymentoftheremaining_______%within_______daysafterthecompletionofthework.Article4ConstructionPeriodTheconstructionworkshallcommenceon_______andisexpectedtobecompletedon_______.Article5QualityRequirementsPartyBwarrantsthattheconstructionworkwillcomplywithrelevantconstructionstandardsandmeetthequalityrequirementsagreeduponbybothparties.PartyAhastherighttoinspectandassessthequalityoftheworkduringandaftercompletion.Article6ObligationsofPartyAPartyAshallprovidePartyBwithnecessaryaccesstotheconstructionsite.PartyAshallmaketimelypaymentsasstipulatedinthiscontract.Article7ObligationsofPartyBPartyBshallcommencetheworkaccordingtotheagreedscheduleandcompleteitwithinthestipulatedperiod.PartyBshallensurethatallconstructionworkmeetsthequalitystandardsandiscarriedoutbyqualifiedpersonnel.Article8SafetyandEnvironmentalProtectionPartyBshallcomplywithallsafetyregulationsandenvironmentalprotectionrequirementsduringtheconstructionprocess.Article9ConstructionDrawingsandTechnicalDocumentsPartyAshallprovidePartyBwithnecessaryconstructiondrawingsandtechnicaldocuments.PartyBshallfollowtheconstructiondrawingsandtechnicaldocumentsfortheexecutionofthework.Article10ChangesandVariationsAnychangesoradditionalworkrequestedbyPartyAshallbedocumentedinwritingandmayresultinadjustmentstothecontractpriceandconstructionperiod.Article11AcceptanceofWorkUponcompletionofthework,PartyBshallsubmitanapplicationforacceptancetoPartyA.PartyAshallconductanacceptanceinspectionwithin_______daysfromthereceiptoftheapplication.Article12LiabilityforBreachofContractIntheeventofbreachofcontractbyeitherparty,thebreachingpartyshallbeliableforanylossesincurredbythenon-breachingparty.Article13ContractTerminationEitherpartymayterminatethecontractbygiving_______days'writtennoticetotheotherpartyincaseofamaterialbreachbythelatter.Article14DisputeResolutionAnydisputesarisingfromtheperformanceofthiscontractshallberesolvedthroughnegotiation.Ifnegotiationfails,eitherpartymaysubmitthedisputeto_______forarbitration.Article15ApplicableLawThiscontractshallbegovernedbyandconstruedinaccordancewiththelawsofthePeople'sRepublicofChina.Article16AdditionalProvisionsAnyadditionalprovisionsoramendmentstothiscontractmustbemadeinwritingandsignedbybothpartiestobeeffective.Article17NoticeAllnoticesandcommunicationsrelatedtothiscontractshallbeinwritingandsenttotheaddressesspecifiedinthiscontractorasupdatedbyeitherparty.Article18ContractEffectivenessThiscontractshallbecomeeffectiveuponsignaturebybothpartiesandshallbebindingonbothparties.PartyA(ClientSignature):_______Date:_______PartyB(ContractorSignature):_______Date:_______(Endofthefirsthalfofthecontract)Article19WarrantyPeriodPartyBshallprovideawarrantyperiodof_______monthsfortheconstructionwork.AnydefectsarisingfromtheconstructionworkduringthewarrantyperiodshallberectifiedbyPartyBatnoadditionalcosttoPartyA.Article20InsurancePartyBshallmaintainallnecessaryinsurances,includingbutnotlimitedtoconstructionallrisksinsuranceandworkers'accidentinsurance.Article21SubcontractingPartyBmaysubcontractpartsoftheworkwiththepriorwrittenconsentofPartyA,butremainsresponsiblefortheperformanceofthesubcontractors.Article22ConfidentialityBothpartiesshallkeepconfidentialallproprietaryandconfidentialinformationobtainedduringthecontractandshallnotdisclosesuchinformationtothirdparties.Article23IntellectualPropertyRightsAllintellectualpropertyrightsrelatedtotheconstructionworkshallbeownedbyPartyA.Article24ForceMajeureNeitherpartyshallbeliableforfailureordelayinperformingtheirobligationsduetoforcemajeure.Theaffectedpartyshallpromptlynotifytheotherpartyofsuchevent.Article25AssignmentNeitherpartymayassignitsrightsorobligationsunderthiscontractwithoutthepriorwrittenconsentoftheotherparty.Article26AmendmentsThiscontractmayonlybeamendedinwritingandsignedbybothparties.Article27SeverabilityIfanyprovisionofthiscontractisfoundtobeinvalidorunenforceable,itshallbeseveredfromthecontract,andtheremainderofthecontractshallcontinueinfullforceandeffect.Article28EntireAgreementThiscontractrepresentstheentireagreementbetweenthepartiesandsupersedesallpriornegotiations,understandings,andagreements.PartyA(ClientSignature):_______Date:_______PartyB(ContractorSignature):_______Date:_______Annexes:AnnexA:ScopeofWorkDetailAnnexB:QualityStandardsandSpecificationsAnnexC:PaymentScheduleandMilestoneDeliverablesAnnexD:ConstructionDrawingsandTechnicalDocumentsAnnexE:WarrantyTermsandConditionsI.AnnexList:AnnexA:Detaileddescriptionoftheworktobeperformed,includingspecifictasksandmaterials.AnnexB:Standardsandspecificationsforthequalityoftheconstructionwork.AnnexC:Breakdownofthepaymentschedulelinkedtospecificmilestonesanddeliverables.AnnexD:Setofconstructiondrawingsandtechnicaldocumentsguidingthework.AnnexE:Termsandconditionsforthewarrantyagainstdefectsintheconstructionwork.II.BreachofContractandDetermination:BreachbyPartyA:Mayincludedelayedpayments,changesinthescopeofworkwithoutpropernotice,orfailuretoprovideaccesstotheconstructionsite.BreachbyPartyB:Mayincludefailuretomeetdeadlines,performworkbelowqualitystandards,orsafetyviolations.DeterminationofBreach:Breachesaredeterminedbasedontheevidenceofnon-compliancewiththecontracttermsandapplicablelaws.III.LegalTermsandDefinitions:ConstructionContract:Aformalagreementbetweenaclientandacontractoroutliningtheworktobeperformed,obligations,andrightsofeachparty.ForceMajeure:Unforeseeableeventsbeyondthecontrolofthepartiesthatprevent履行contractualobligations.WarrantyPeriod:Aspecifiedtimeframeaftercompletionofworkduringwhichdefectsarerectifiedbythecontractor.