建设工程设计合同(2014年中英版)

建设工程设计合同ConstructionProjectDesignContract项目名称：ProjectName:项目建设地点：ProjectLocation:合同编号：ContractNo:设计资质等级：GradeofdesignLicense:托付方：Client:设计方：DesignFirm:签订日期：Signeddate:托付方（甲方）：Client(PartyA):设计方（乙方）：DesignFirm(PartyB):甲方托付乙方担当【】工程设计，经双方协商一样后，签订本合同。PartyAentrustsPartyBtoundertakethedesignfor【】thiscontractismadebythetwopartiesaftertheirmutualagreement.本合同依据下列文件签订Article1.ThisContractismadeonthebasisofthefollowingdocuments1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计管理条例》。《TheContractLawofthePeople’sRepublicofChina》,《ThebuildingregulationsofthePeople’sRepublicofChina》and《RegulationsonAdministrationofSurveyingandDesigningofConstructionProjects》.1.2国家及上海市有关建设工程勘察设计管理法规和规章。RelevantBuilding&DesignCodesandRegulationsoftheStateandoftheShanghaiMunicipality.1.3建设工程的相关批准文件。1.3Theapprovaldocumentsthatarerequiredforthisconstructionproject.其次条本合同工程设计项目的名称、地点、规模、投资总额、内容及标准Article2.Thename,location,size,investmentsum,function,designcontentsandstandards2.1工程项目名称：【】2.1Projectname:【】2.2工程项目地点：【】2.2Projectlocation:【】2.3工程项目规模：【】2.3Projectsize:Thetotalfloorareaisapproximately【】m2(ofwhichthefloorareaoftheundergroundareais【】m2),thetotalheightis【】m.2.4工程特征及附注说明：【】2.4Projectfeatures&remarks:【】2.5工程项目投资总额：【】2.5Projectinvestmentintotal:ControlledWithinRMB【】millionyuanRMB.2.6工程项目的设计内容及标准：【】2.6Designrequirementsandscopeofwork:【】第三条甲方向乙方提交的有关资料及文件Article3.RelevantdocumentswhichshallbeissuedbyPartyAtoPartyB序号S/N数据及文件名称Nameofdocuments份数Copies提交时间SubmissionDate备注Remarks政府批文GovernmentApprovalDocuments设计任务书DesignInstructions规划红线图PlanofPropertyLine水、电、气源落实状况说明DesignInformationofUtilities(water,electricity&gassupplyetc.)规划设计要求RequirementsfromtheGovernment地质勘探报告SoilinvestigateReport原打入桩的资料DesignInformationofAsBuiltpilings概念方案ConceptDesignInformation第四条乙方向甲方交付的设计文件Article4.DesigndocumentswhichshallbesubmittedbyPartyBtoPartyA(listedasfollows):序号S/N设计文人名称DesignDocuments阶段Phase份数Copies提交时间SubmissionDate备注Remarks方案设计文件SchematicDesignDocuments方案Schematic初步设计文件D.D.Documents扩初初步概算文件PreliminaryEstimate扩初施工图设计WorkingDrawings施工图ConstructionDocuments光盘文件CDfiles施工图C.D注：设计文件深度依据《建筑工程设计文件编制深度规定》（建设部2008年版）执行。Notes:Thedesigndocumentsshallbepreparedincompliancewiththe<Regulationsondetailrequirementsofdesigndocumentsforconstructionproject>(issuedbyMinistryofConstructiondatedin2008).第五条设计费用及支付方法Article5.Designfeeandthemodeofpayment5.1甲方应支付本合同项目的设计费为【】（已含全部由乙方应缴纳的税费及其它政府规定应由乙方缴纳的款项）5.1PartyAshallpaythedesignfeeofRMB【】yuanforthisprojecttopartyB(ThisfeeshallincludetaxesandallotherdutiesthatshouldbepaidbyPartyBasrequiredbythegovernmentregulations).5.2支付方法（见下表）：5.2Thepaymentmethodis(listedasthefollowing):序号阶段Phase金额Amount(yuan)说明Remarks方案阶段SchematicDesign扩初阶段DesignDevelopment施工图阶段ConstructionDocument施工协作Constructioncoordination竣工验收阶段TheCompletion&Handingoverstage第六条甲、乙双方的责任Article6.Responsibilitiesofbothparties6.1甲方责任6.1ResponsibilitiesofPartyA甲方应依据本合同第三条的约定，在规定时间内向乙方提交数据及文件，并对其完整性、正确性刚好限负责。甲方提交上述数据及文件超过规定期限15天以内的，乙方按本合同第四条规定交付设计文件时间相应顺延；超过规定期限15天以上的，乙方有权重新确定提交设计文件的时间。6.1.1AccordingtothecontentsstatedinArticle3ofthisContract,PartyAshallsubmitmaterialsanddocumentstoPartyBwithinthestipulatedtimeasdescribedandshallberesponsibleforthecompleteness,correctnessandvalidityofsuchmaterialsanddocuments.IntheeventthatPartyAhasdelayedtheissuanceofsuchmaterialsanddocuments,butnotexceeding15daysfromthestipulatedtime,PartyBcouldconsequentlypostponethesubmittalofthedesigndocumentsasstipulatedinArticle4ofthisContract.IncasethatPartyAhasdelayedtheissuanceofmaterialsanddocumentsformorethan15daysexceedingthestipulatedtimelimit,PartyBshallhavetherighttodeterminethenewdateforsubmittingthedesigndocuments.6.1.2甲方变更托付设计項目、规模、条件，或对提交数据作重大修改，以致造成乙方设计需返工时，甲、乙双方除需另行协商签订补充合同、重新明确有关条款外，甲方应按乙方所耗工作量向乙方支付返工费用。6.1.2IfPartyAaltersgreatlythedesignproject,scale,conditionwhichtheyhavealreadyentrustedtoPartyB,orthematerialsprovidedbyPartyAiswrong/incompleteorPartyAmakesmajoralterationstotheapproveddesignandtheinformationgiven,asaresultofwhich,hascausedPartyBtoredothedesignwork,orhasgeneratedun-necessaryabortiveworks,bothpartiesshallenterintonegotiationandtodrawupasupplementarycontract.PartyAshallcompensatePartyBfortheadditionalworkloadinaccordancetothenewagreement.在合同履行期间，甲方单方提出解除合同的，乙方已起先设计工作的，甲方应依据乙方已进行的实际工作量支付设计费。6.1.3ShouldPartyAterminatetheContractduringthecontractualperiod,partyAshallpayPartyBaccordingtotheactualworkdone.甲方在收到乙方付款通知书后30天内，按本合同第5条规定的金额和时间向乙方支付设计费用；在收到付款通知书的60天仍未支付，每逾期支付一天，应担当设计费金额千分之一作为逾期违约金。逾期超过30天以上的，乙方有权暂停履行以下阶段工作，并书面通知甲方。行政主管部门对设计文件不予审批或本合同项目停缓建，甲方均应支付应付的设计费。6.1.4PartyAshallpaythedesignfeetoPartyBwithinThirty(30)daysuponreceivingtheNoticeofPaymentfromPartyAaccordingtotheamountandthetimestipulatedinArticle5.IncasethatsuchpaymentisdelayedforSixty(60)daysuponreceivingtheNoticeofPayment,thenapenaltyof0.1%ofthedueamountofpaymentonadailybasisshallbepaidbyPartyA.incasethatsuchpaymentisdelayedforaperiodover30days,PartyBshallhavetherighttosuspendtheirdesignworkforthenextphaseandshallinformPartyAinwriting.IncasethatthemanagementofPartyAdoesnotapprovethedesigndocumentsortheconstructionoftheprojectofthisContractisstoppedor..postponed,PartyAshallneverthelesspayduedesignfee.甲方要求乙方比合同规定时间提前提交设计文件时，甲方应支付赶工费。6.1.5IfPartyArequestsPartyBtosubmitthedesigndocumentsaheadofthestipulatedofthestipulatedtimeasmentionedintheContract,PartyAshallmakeadditionpaymentforfastandimmediateservice.为乙方派往现场的工作人员供应工作便利条件。6.1.6PartyAshallprovidesiteofficeandallrelevantofficestationaryforPartyB’spersonnelwhoarebeingsenttoworksiteduringtheconstructionstage.甲方应爱护乙方的设计版权，未经乙方同意，甲方对乙方交付的设计文件不得复制或向第三方转让或用于本合同以外的项目，如发生以上状况，乙方有权向甲方索赔。6.1.7PartyAshallprotectthedesigncopyrightofPartyB.WithoutPartyB’sconsent,PartyAshallnotduplicateoftransfertoathirdpartyorusethedesigndocumentsforotherproject.Oftheabove-mentionedishappened,PartyBshallhavetherighttoclaim.6.2乙方责任6.2ResponsibilitiesofPartyB:乙方按本合同第四条规定的内容、时间及份数向甲方交付设计文件。6.2.1PartyBshallsubmittoPartyAtherequireddesigndocumentsinrightcontent,timeandcopiesaccordingtotheclauseofArticle4.乙方对设计文件出现的遗漏或错误应在施工前负责修改或补充。由于乙方设计错误造成工程质量事故损失的，乙方除负责实行补救措施外，应免收损失部分的设计费，并依据损失程度向甲方偿付赔偿金，赔偿金额依据乙方与保险公司签订的设计责任保险合同计算。6.2.2PartyBshallberesponsibleforcorrectinganyomissionormistakeintheirdesigndocumentsbeforetheconstruction.IfthedesignmistakemadebyPartyBhascausedlossestoPartyA,PartyBshallnotonlyberesponsiblefortakingtheremedialmeasures,butalsoshallremitthedesignfeeforthepartofsuchlossesandshallpaycompensationtoPartyAaccordingtothedegreeofsuchloss.TheamountofthecompensationshallbedeterminedbypartyBandhisinsurancecompanyandtobeinaccordancetotheprofessionalindemnityinsurancecoverage.由于乙方自身缘由，延误了按本合同第四条规定的设计文件交付时间，每延误一天，应减收该项目应收设计费的千分之一。6.2.3IfitisPartyB’sownfaulttohavedelayedthesubmissionofthedesigndocumentsaccordingtothestipulatedtimeasdescribedinArticle4,PartyBshalldeduct0.1%ofthedueamountofthedesignfeeinadailybasisforthedelayperiod.6.2.4合同生效后，乙方单方提出解除合同的，乙方应当依据有关规定赔偿甲方损失。6.2.4AftertheContractcomesintoforce,ifPartyBproposestoterminatetheContract,PartyBshallcompensatePartyA’slossesaccordingtotherelevantregulations.乙方交付设计文件后，应参与甲方及相关职能部门的设计审查会议及依据审查结论负责不超出原定安排任务书范围内的必要调整补充；负责向甲方及施工单位进行设计交底，处理有关的设计问题和参与竣工验收。乙方应派相关人员参与施工期间的例会。乙方应优化设计以帮助业主将造价限制在预算内。6.2.5Afterthedesigndocumentshasbeensubmitted,PartyBshallalsoattendtheapprovalmeetingsheldbyPartyAandtherelevantcompetentauthoritiesandshallberesponsibleformakingthenecessaryadjustments,revisionsandsupplementswhichdoesnotexceedthescopeofthedocumentsofdesignrequirementasoriginallydefinedbasedonthecommentsofsuchmeetings.PartyBshallberesponsibleforsolvingalltherelevant乙方不得向第三方扩散、泄漏、转让甲方提交的产品图纸技术经济资料。如发生以上状况，甲方有权向乙方索赔。6.2.6PartyBisnotallowedtodisclosedandtransfertoathirdpartyanyproductdrawing,technicalandeconomicdataetc.whichareprovidedbyPartyA.Incasethattheabove-mentionedishappened,PartyAshallhavetherighttoclaim.未经甲方同意乙方不得将本项目的设计工作全部或部分转包给第三者。PartyBisnotallowedtosubcontractthedesignworkcompletelyorpartiallytoanythirdpartywithoutthepermissionofPartyA.第七条其他约定Article7Otherprovisions7.1甲方要求乙方指派专人长期驻施工现场进行协作与解决有关问题时，双方应另行签订技术询问服务合同。7.1WhenPartyArequiresPartyBtosendsitepersonneltotheconstructionsiteforalongperiod,thetwopartiesshallnegotiatefortheseadditionalworkandsignasupplementaryserviceContract.7.2乙方为本合同项目所采纳的国家或地方标准图，由甲方自费向有关出版部门购买。7.2PartyAshallpayforalltherelevantpublicationsandstandardcollectionsofdrawingsissuedbythestateandlocalgovernmentwhichareneededbyPartyBforthepurposeofdesigningtheproject.7.3本合同第四条规定乙方交付的设计文件份数超过本合同第四条规定的份数，乙方另收工本费。7.3IfPartyBisrequiredtosubmitdesigndocuments,ofwhich,thenumberofcopiesaremorethanthosestipulatedinArticle4ofthisContract,PartyAshallpayforthoseadditionalcopies.7.4本工程项目中，建筑材料、设备的加工订货，甲方须要乙方设安排人员协作时，所需费用由甲方担当。7.4IfPartyArequirePartyBtoprovidepersonneltoassistthemforprocurementpurposes,suchastheprocurementofbuildingmaterial,equipmentandetc;theexpensesneededshallbebornebyPartyA.7.5甲方托付乙方担当本合同内容之外的工作服务，另行支付费用。7.5IfPartyAentrustsPartyBtoundertakethoseworkandserviceswhicharebeyondthisContract,PartyAshallpayadditionalfee.7.6由于不行抗力因素致使合同无法履行的，双方应刚好协商解决。WhenthisContractcan’tbeexecutedbecauseoftheunforeseeablenaturalforces,thetwopartiesshalltimelynegotiatetosolvetheproblem.7.7本建设工程设计合同在履行过程中发生纠纷，双方应刚好协商解决。协商不成时，双方同意由上海市仲裁委员会仲裁。7.7BothpartiesshalltimelydiscusseachotherforthesettlementofanydisputearisingduringtheexecutionofthisContract.Incasethatsuchdiscussionfails,bothpartieshaveagreedappealingtoShanghaiMunicipalArbitrationCommissioncanbeaccepted.7.8甲方聘请【】为甲方顾问，帮助甲方进行设计管理和建筑设计询问。费用由甲方另行支付。7.8PartyAhasengaged【】toactasPartyA’sconsultantstoassistPartyAtoprovidethedesignmanagementanddesignconsultationservices.ThefeewillbepaidbyPartyAdirectlyandseparately.7.9本合同未尽事宜，双方可签订补充协议，补充协议与本合具有同等效力。Supplementaryagreementcouldbemadebetweenthetwopartiesincasethatanyadditionalclauseshallbeadded.Thesupplementaryagreementshallhavethesameeffectandpowerasthiscontract.7.10本合同一式八份，甲方执肆份，乙方执叁份，政府部门执壹份。7.10Thiscontractshallbemadein8copies.PartyAshallhold4copies.PartyBshallhold3copies.Thegovernmentauthoritydepartmentshallhold1copy.7.11本合同以中英比照书写，如有冲突，应以中文文本为准。7.11ThisContractispreparedinbothChineseandEnglishlanguages,intheeventofconflictsinanyoftheprovision