ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT合同范本.doc

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT合同范本 EX-10.12dex101.htm ENGINEERING,PROCUREMENT ANDCONSTRUCTION AGREEMENTExhibit10.1FOIA CONFIDENTIAL TREATMENT REQUESTEDPORTIONS OFTHE EXHIBITSHERETO MARKEDBY*HAVE BEENOMITTED PURSUANTTO AREQUEST FORCONFIDENTIALTREATMENTFILED SEPARATELYWITH THESECURITIES ANDEXCHANGE MISSIONENGINEERING,PROCUREMENT ANDCONSTRUCTION AGREEMENTBETWEEN MIRANT MID-ATLANTIC,LLC&MIRANT CHALK POINT LLC(EACH INDIVIDUALLYAN“OWNER”AND COLLECTIVELYTHE“OWNERS”)AND MIRANTMID-ATLANTIC,LLC ASAGENT FORTHE OWNERSAND STONE&WEBSTER,INC.(“CONTRACTOR”)FOR ENGINEERING,PROCUREMENT&CONSTRUCTION SERVICESRELATING TOAIR QUALITYCONTROL SYSTEMSAT MORGANTOWNGENERATING STATION,DICKERSON GENERATING STATION ANDCHALK POINTGENERATINGSTATIONTABLE OFCONTENTS PAGE1.DEFINITIONS12.OWNER ENTITIES.2irant Mid-Atlantic,LLC Mirant Chalk Point,LLC Mwners AgentO bligationsO11111112123.EFFECTIVE DATE4.TERM5.OWNER SCOPE5.1Owner Scope5.2Gypsum DewateringPlant5.3Schedule forOwner Scope5.4Non-Interference andSafety6.PROJECT SCOPE6.1Work ToBe Performed6.1.1LNTP for FGD Systems6.1.2INTP for FGD Systems6.1.3NTP for FGD Systems6.1.4LNTP forSCR System6.1.5INTP forSCR System6.1.6Transition ofSCR fromContractor toOwner6.1.7Application ofTerms andConditions6.2Engineering/Design Services6.2.1Technical Specifications6.2.2Design Standards6.2.3Design DocumentationSchematic DesignDocumentsPermitting DocumentsD esignDevelopment DocumentsA pprovedDrawingsR oughSite Grading,Demolition andRelocationI nterfacesand connectionsfor theGypsum DewateringPlantC ontractors Obligationsunder Section6.3Procurement Services6.3.1Procurement ofSystems Equipment and Construction Equipment i12121212131315151515151516161616171717171718181920222223Title toSystems EquipmentRisk ofLossStorage6.3.2Procurement ofChemicals,Start-Up Sparesand Consumables6.3.3Inspection and Testing ofMaterials andSystems Equipment6.4Transportation Charges6.5Construction-Related Work6.5.1Clearance of the Site(by Owner)23323242424224246.5.2Labor andPersonnel6.5.3Construction UtilitiesInterface6.5.4Testing6.5.5As-Built Drawings6.5.6Operation andMaintenance Manuals6.5.7Turnover Package6.5.8Clean Upand WasteRemoval6.5.9Hazardous Substances6.5.10Quality Assurance/Quality Control6.6General6.7Non-Interference6.8Safety6.8.1Contractor ResponsibilityFitness ForDuty,Drug,Alcohol AbuseAnd SafetyPolicy ForAess To6.8.2Owner Facilities6.8.3Aess ToOwner Facilities6.8.4Prohibited Activities6.8.5Suspected ViolationOf Policy6.8.6Refusal ToComply6.8.7Protection6.8.8OSHA Compliance6.8.9Material SafetyData Sheets6.8.10Dust andFume Control6.8.11Water Pollution6.8.12Operating EnvironmentGenerating SitesElectrical System6.9Operating UtilitiesInterface6.10Owners Right to Inspect,Stop andRe-Perform Work6.10.1Owners Right to AttendContractor Inspections6.10.2Inspection andRe-Performance7.PERFORMANCE GUARANTEES7.1I nputGuarantees forFGD Systems7.1.1Guaranteed ConsumptionLevels25252525252626262728282929293030303131323232323232333333333333333.3Consumption WithinEngineering Design Margins ConsumptionOutside EngineeringDesignMarginsii3434.1.47Liquidated Damagesfor InputGuarantees forFGD SystemsPower ConsumptionMake-Up WaterConsumptionLimestone Consumption344334347.2Output GuaranteesforFGD Systems7.2.1List ofOutput Guarantees7.2.2Correction by Contractor7.2.3Mercury Removal7.3Operational GuaranteesforFGDSystems7.3.1List ofOperational GuaranteesM inimumTurndown CapabilityM aximumEntrained MoistureCarryoverF anCharacteristicsP ressureDrop7.3.2Correction by Contractor7.4Blank7.5Blank7.6Blank7.7Performance Testing7.7.1Performance Testing7.8Concurrent Obligations8.PROJECT SCHEDULE;SCHEDULE GUARANTEES8.1Project Schedule8.1.1Guaranteed Provisional Aeptance Date8.1.2Conditions forOutages8.1.3Outage Startand EndDates8.1.4Blank8.1.5Concurrent Outages8.1.6Immovable Milestones8.2Schedule Guarantee8.2.1Work Progressand CompletionG eneralM aximumOutage Period.1Amounts Reasonable.2Bonus forEarly Completion.3Payment ofExcessive OutagePayments8.2.2Guaranteed Provisional Aeptance Date8.2.3Late Provisional Aeptance Payments3434353536363636363636363636363637373738383838383939393939404141414.2.3.38Before23:59on December31,xxfor theFGDSystemsAfter23:59on December31,xxforFGDSystems lank Biii4142Reduced Late Provisional Aeptance Payments PeriodAmounts ReasonablePayment ofLateProvisionalAeptancePayments4243438.2.4Guaranteed Substantial Completion DateLate Substantial Completion PaymentsAmounts Reasonableand ExclusiveRemedy forDelayPayment ofLate SubstantialCompletion Payments8.2.5Guaranteed Final Completion Date8.2.6Late Final Completion PaymentsAmounts Reasonableand ExclusiveRemedy forDelayPayment ofLate FinalCompletion Payments8.2.7Full ProgramCompletion8.2.8Reduction ofLiquidated DamagesBased onDelayed Permitting8.3Schedules8.3.1Schedule Software8.3.2Activity Coding8.3.3L evel3Detail8.3.4S cheduleUpdates8.4Work Operations8.5Recovery Schedule8.6Critical ScheduleSituation8.7Contractor Responsiblefor Schedule9.K EYPERSONNEL REQUIREMENTS9.1Personnel Resources9.1.1Key Personnel9.1.2D epartureof Key Personnel9.1.3A ssignmentof Key Personnel9.1.4Replacement of Key Personnel9.1.5Key Personnelof Subcontractors9.2Contractor PersonnelTransition Plan9.2.1N oticeof DepartureofKeyPersonnel9.2.2M utualAgreement9.3Independent Contractor:Employees9.4Applicable TimePeriod10.TARGET COST444444444545454546464747474747474848484848484949495050505051515110.110.2Facility Target Cost Calculationof Contractors Actual Cost0.2.1ategories of Costs1C0.2.2ctual HomeOffice LaborCosts1Aiv5151152510.2.3Actual FieldNon-Manual LaborCosts10.2.4Actual Self-Performed FieldManual ServicesCost525210.2.5Actual Third Party Expenses10.2.6Selling,General andAdministrative Expenses10.2.7Separate Aounts10.3Cap onContractors TotalEngineering Hours11.PRICE11.1EPC TotalCompensation11.2P rojectCompensation11.3Guarantee Costs11.3.1Classification ofGuarantee Costs11.3.2Treatment ofGuarantee Costs11.4Incentives11.4.1Blank11.4.2Performance IncentivesEarly Completion of WorkDuring PlannedOutagesS afety,Schedule andQuality Incentive11.5Allocable Costs11.5.1Sections AddressingAllocable Costs11.5.2Treatment ofAllocable Costs11.6Underrun Bonus12.PAYMENT TERMS12.1Payments Generally12.1.1Owner ShallPay ContractorEPC TotalCompensation12.1.2Milestone-based,Guarantee andFinal Payments12.1.3NTP Milestone Payment12.2Milestone ProgressPayments12.2.1Approved Final Milestone Payment Schedule12.2.2Milestone ProgressPayments12.2.3Partial PaymentRequests12.2.4Valid PaymentRequests12.2.5Documentary Evidenceof AchievingMilestone12.2.6Owner Review12.2.7Payment ofMilestone Paymentshall notconstitute approvalor5353545454545454545556565656565858585859595959595959596061616161aeptance ofWork by Owner12.3Quarterly Reconciliation2.3.11Timing ofQuarterly Reconciliation2.3.2cheduled Milestone1S2.3.31Inplete Milestone2.3.4uarterly ReconciliationRatio1Q2.3.5uarterly Actual Cost and Disputed Costs1Q12.3.6Reconcilable Cost12.3.7Quarterly MilestonePayment Cost2.3.8uarterly Benchmark Cost1Qv6116162626266262262.412.512.612.712.812.912.10112.3.9Performance ofReconciliationExcess PaymentPayable Cost2.3.101Reconcilable Costgreater thanQuarterly BenchmarkCostSupplemental Contingency Draw RequestDifference betweenQuarterly MilestonePayment Costand QuarterlyBenchmarkCost12.3.11Carryover Cost12.3.12NTP MilestonePayment addedto QuarterlyActualCostin13th monthlankBLate PaymentInterest ontingencyC2.6.1Q uarterlyContingency AllowanceLimit12.6.2C ontingencyDraw Request112.6.3ContingencyDrawNotification12.6.4Owner Approvalof ContingencyDraw Requesturpose ofQuarterly ReconciliationProcess Petention Rffect ofChange Orderon Approved FinalMilestonePaymentScheduleE onditionsof Payments;Withholdings,Set-Offs C12.10.1Material Breach12.10.2Required SubmittalsProgress Reportsartial Lien Waivers Pull LienRelease Form ofWaivers and Releases Fien BondsL12.10.3Withholding toProtect Ownerfrom LossOwner maywithhold orretain anyMilestone Progress636336363636646446464646466565565666666666666666767667767Payment,payment orpart.1Contractor Eventof Default12.1.2Lien orCharge NotDischarged.3Work Performedby OwnerLien BondsPayment afterRemoval ofCause12.10.4Set Offinal Paymentfor TargetWork atEach FacilityF2.11.1pen BookBasis ShowingActual Costs1O12.11.2Target Final Payment12.11.3Target Final Payment Documentationinal lienwaiver Fs-Built DrawingsAperating manualsOvi676886868686866969969696Warranty documentsBack-charges and/or claimssatisfiedQuality andreliability requirementsNonconformance itemsSpare partslistMill certifications12.12Liens AfterFinalPayment12.13Payment ofGuarantee Costs12.13.1Separate Aounting12.13.2Prior toTarget FinalPayment12.13.3After TargetFinalPayment13.PRICING METHOD699696969669690707070770707071717172727273737373737413.113.2Blank TargetPrice Method14.WARRANTIES14.4arts and Labor WarrantiesP4.1.11Warranties4.1.2P artsandLabor Warranty Period14.1.3C onditionsand Limitationsof Warranty114.1.4Repair ofDefects14.1.5Parts andLaborWarrantyPeriod ExtensionE xtensionfor CorrectedWorkE xtensionfor TotalShutdown lankB ggregationof Warrantiesand SpecificTime LimitationA NoOther Warranties/Obligations15.STANDARDS OFPERFORMANCE16.MECHANICAL PLETION16.1M echanicalCompletion16.2Notice andAchievement ofMechanical Completionfor EachSystem17.PROVISIONAL ACCEPTANCE/SUBSTANTIAL PLETION17.417.517.617.717.8riteria forProvisionalAeptance of FGDSystem Criteria forSubstantialCompletionof FGDSystem otice andReport of ProvisionalAeptancefor EachSystem AchievementofProvisionalAeptanceof the Workreation ofPunch-List otice andReport of SubstantialCompletionfor EachSystem chievementofSubstantialCompletionof the WorkA ransferof Possessionand Controlof the Systems toOwner Tvii18.FINAL PLETION7474747575757676767777777878equirements Rotice andReport of FinalCompletionN AchievementofFinalCompletion7879797979797980808081818181828219.CHANGE ORDERS19.419.519.619.719.819.919.1019.119.121hanges Crocedure forChanges P9.2.11Changes Initiatedby Contractor9.2.21Changes Initiatedby Owner9.2.31Change inCost Elementand FeeElement Change Order Due to Force Majeure EventChange Order DuetoSuspension ofWork byOwner hangeOrder Dueto DifferingSite ConditionsC Change Order Dueto Pre-Existing HazardousSubstances hangeOrder Dueto Actionsof OwnerC lankB hangeOrder Dueto Changesin Applicable Law CChange Order Dueto Escalationin Actual Self-Performed FieldManual ServicesCost ChangeOrder Dueto Escalationin HomeOffice LaborCosts andActual Field823838Non-Manual LaborCosts ChangeOrderDueto Escalationof Commodities19.1319.149.1519.1619.171Changes InvolvingSchedule ExtensionsChanges tothe Contract Price ContinuedPerformance PendingResolution ofDisputes wners Right to OffsetChanges Other Workon SiteO838348585820.FORCE MAJEURE20.4orceMajeureF Burdenof ProofObligations Excusedosts C8585868686868686878787888888888921.AGGREGATE LIABILITY21.421.521.6ggregate LiabilityA ub-limits of Liability S21.2.1Liquidated Damagesand WarrantyWork21.2.2Systems EquipmentSubcontractors21.2.3Other Subcontractors21.2.4Facility Limitsursuit ofSubcontractor WarrantiesP onsequential Damages ConsequentialDamagesfor SubcontractorsC Indemnityfor LessorClaims viiiS ECURITY222.322.4ontractors ParentCompany GuaranteeC ontractors Letter of CreditC PerformanceBond andPayment BondOwner Security8998989090S USPENSIONAND TERMINATION23.23.1RighttoStop Workfor Cause23.2RighttoSuspend Workfor Convenience3.3uspension byContractor S23.4ermination byOwner forConvenience T23.4.1ighttoTerminate R23.4.2ermination PaymentT23.4.3ithholding/Conditions PrecedentW223.4.4Return ofSecurity23.5Termination byOwner forCause3.5.1Insolvency291919292929292939393943.623.7223.5.2Delay AfterProvisionalAeptance23.5.3KeyPersonnel3.5.42Material BreachActions UponTermination urvival S949449494924.ASSIGNMENT I25.NSURANCE25.1Contractors Insurance25.1.1Casualty InsuranceCommercial GeneralLiability InsuranceBusiness AutomobileLiability Insurance5.1.2orkersCompensation and Employers LiabilityInsurance W25.1.3ontractors PropertyC225.1.4Transit Insurance25.1.5Other InsuranceInternational InsuranceDifferences inCondition Policy5.1.6eneral InsuranceConditions G25.1.7ther Duties,Representations,and ObligationsOCertificates ofInsuranceViolation ofInsurance TermsFailure toMaintain InsuranceNo Waiver ofLiabilityAdditional InsurancePremium Audit5.1.8ubcontractors InsuranceS2ix25.2.T IME26.949595959596969696979797979797989898989898Levels ofCoverageWaiverofRights Owners Insurance5.2.1uilders AllRisk2B25.2.2Exclusion fromBuilders Risk25.2.3Contractor Compliance98999999999999100100100100T AXES27.7.1Taxes27.2S alesTaxes27.3P ropertyTaxes228.INDEMNIFICATION10028.1Property Damage28.2Limitation onProperty DamageIndemnification28.3Royalties andLicense Fees28.4Operation ofSystems28.5No Liensor Encumbrances28.6Contractors Indemnitiesfor PersonalInjury orProperty Damage28.7Other Contractors Indemnities28.8No Limitationto WorkersBenefits29.GOVERNING LAW30.PERMITTING30.130.2esponsibility forPermitting R0.1.13Owners PermitsRequired forConstruction30.1.2Permission toBegin Installationof PilingsOther Permits10010110110110110110210210210210210310310310310310310310410410410410410410510510510631.SITE CONDITIONS31.1Geotechnical Study31.2Special SiteCharacteristics Contractors Knowledgeof Conditions31.331.4Sub-Surface SiteConditions32.SUBCONTRACTORS32.1Approved SubcontractorsS ubcontractorand VendorIdentification32.232.3Substitute Contractors32.4Purchase Ordersand Subcontracts32.5Subcontractor Warranties32.6Subcontractor Insurance32.7No Privitywith Subcontractors32.8Assignment ofSubcontracts toOwner x2.9D irectedPayments32.103Neglect toPay10606133.DISPUTE RESOLUTIONApplicability ofResolution Procedures33.133.2Management Discussions10610610633.333.43.533.633.733.83Mediation ArbitrationDispute ReviewBoard bligationsContinue OInjunctive ReliefurvivalS10710708108109109134.MISCELLANEOUS34.434.534.634.734.834.934.1034.1134.1234.1334.1434.1534.1634.1734.18Audit andMaintenance ofRecords Rightsto WorkProduct34.2.1eliverables D34.2.2icense L34.2.3euse Rompliance withLaws C34.3.1Familiarity withLaws34.3.2No Feesor Commissionsuthorized RepresentativesA onfidentialityC34.5.1onfidential InformationC34.5.2ondisclosure N34.5.3ompelled DisclosureC34.5.4Use RestrictionsOwner CausedProject EndSuspension andOther OwnerCaused Eventotices Nelationship of the PartiesR mendmentsA oThirdPartyBeneficiaries Nriority AmongContract DocumentsP SeverabilityRemedies onwaiverN Interpretationntire AgreementE epresentationsand Warranties of ContractorR34.17.1Due Organization of Contractor34.17.2Due Authorizationof Contractor,Binding Obligation34.17.3Non-Contravention4.17.4R egulatoryApprovals3epresentation andWarrantiesof Owner R4.18.1D ueOrganizationofOwner3xi10910910910910910911011011011011011011111111111111211311411411411411411411411511511511611611611611634.18.2Due AuthorizationofOwner;Binding Obligation11634.1934.2034.2134.18.3Non-Contravention FurtherAssurances oImplied WaiverN xhibitsand SchedulesExii116117171171TABLE OFEXHIBITS EXHIBITNUMBER FGDTechnical Specification1TITLE2FGD Divisionof Responsibility3Intentionally OmittedPermitting Divisionof Responsibility4Intentionally Omitted5Performance GuaranteesandTestMethods6KeyPersonnel7Cost Submittedwith Proposal88A DetailedCost Summary8B DetailsofCostContractors Technicaland CommercialClarification/Exceptions8C RateSheet8D Intentionally Omitted8E Escalationof Commodities8F9Progress MilestonePayments10Applicable Codesand StandardsLetterofCredit11Payment Bondand PerformanceBond12Agency Letter13IntentionallyOmitted14Draft ProjectSchedule1516Forms forLienWaiversandReleases17Dispute ResolutionBoard ProcedureENGINEERING,PROCUREMENT ANDCONSTRUCTION AGREEMENTTHIS ENGINEERING,PROCUREMENT ANDCONSTRUCTION AGREEMENTis madethis30th dayof July,xx,by andbetween MIRANTMID-ATLANTIC,LLC,a Delawarelimited liabilitypany,and MIRANTCHALKPOINT,LLC,a Delawarelimited liabilitypany(each individuallyan“Owner”,or collectively,“Owners”as furtherdescribed in Sections2.1and2.2),MIRANTMID-ATLANTIC,LLC asagent for the Owners,and STONE&WEBSTER,INC.,a Louisianacorporation(“Contractor”).NOW,THEREFORE,for andin considerationofthemutual covenantsset forth in thisAgreement,the Partiesagree asfollows:1.DEFINITIONS1.1“ActualCost”is thesum ofall actual costs forperforming the Work asdescribed in Section“Actual FieldNon-Manual LaborCosts”has themeaning set forth inSection.3“Actual HomeOffice LaborCosts”has themeaning setforth inSection.4“Actual Self-Performed FieldManual ServicesCosts”has themeaning setforth inSection.5“Actual ThirdParty Expenses”has meaning setforth inSection.6“Agreement”means thisEngineering,Procurement andConstruction Agreement,consisting ofArticles1through34,and Exhibits1,2,4,6through13,15through17.1.7“Alliance Agreement”means theagreement betweenOwner andContractor datedJuly11,xxpursuant towhich preliminaryWork hasbeen performedas authorizedbyOwnerthrough theissuance ofLNTP andINTP.1.8“Allocable Costs”has themeaning setforth inSection.9“Applicable Laws”means alllaws,statutes,ordinances,rules,regulations,judgments,interpretations,policies andorders of any court,arbitrator orgovernmental agencyor authorityhaving orasserting jurisdictionover theFacility,the Site,the Systemsor theperformanc